HomeMy WebLinkAboutC84-026 Asbescoc
AK-1-7/R4
CONTRACT FOR REMOVAL AND/OR -
ENCAPSULATION OF ASBESTOS PRODUCTS
PIP"
THIS ACrFEMENT Piad-i this 31 clay cif _aqe�e 198 by and between
ASRESCO, INC., A Colorado Corporation, hereinafter known as "Asbestos Contractor",
1 q �L) el Ol � , hereinafter known as "Oviner" , for the
rem��
oval n( or encapsu Ation of asbostos products, said work
k to be performed as more
fully scat forth :-)n Fxhibit "A" atta,:hod horeto and incorporated :)y roferrnce herein,
and to bp perfort•led at tho real proj)erty or prope-rti es as more fully described on
Exhibit "B" attachod h,2reto ani i nenr,):)rated by rein Bey refort�nce .
A propnsi:l �'r(;i;.ir >~ri 3iC1 �.'i:('� I;r o-1 by tilt-sht.stoc r ntractnr and accepted by
the Own-r b dit inn. -i!� ! ,x:• -!irin• *,ha act-Pptance section of the proposal shall hP
considnrel iIvir as a s:rh5tlttlt', ,ind ro,,1.1C►'lllont for EXtllhlt "A".
Cn':TRACT DOCUMENTS
Thr! cnrltr:ict doct,;;v•rite, cnr.si ;t of this a �rptvient, Fxhi hi is "A" and "['," all
listed attachrion`s whort' itldic•ltid ',fith ,in "V, plans and Spr?C.iflcations if any, and
ovidenco of ins;,rance arr.1 dorforl•iaor-� hn,nds(if requirr?d), A:vl,-�ndiiv-�nts, Add,nduns ?nci
i,harl t� 7r(�ir ; sha 11 rt1 see t,-, i n-nrltr ra+ed i nto this a jr-,omont it oxr?cutod by the
partit's hereto, and shall be offoc.tivo ille late of such expctltion.
- ATTACHNENTS
All At-ach,ilo?its 1is;ei !)oloa :ind indi,_atel as applicable by an "X" in the
left column arF� a dart of ind i ncorporatc d horpi n .
X
I.
D,- firlitirn
K
?,
Containment Area ' control
K
?.
!lork Area Procedures
X
4.
Codas and Rey>> l ration s
S.
F.sta!bl i shi n y the Containment Area (s)
6).
Removal Procedures
7•
Abaterlont of Cont a:air.,�tc--d Soils
X
8.
Testi n�j and Hnni tori ny
9.
Tools and rEquilwi,1 nt
10.
Cl Pail-::1; iind Disposal
X
11.
Final Ire select i on ,ind Accoptance
X
12.
Submittal s
MATERIAL, PERFORMANCE AND LABOR
\%N -\%vwi
r
r The Ashes tos Contractor agrees to provide all materials, tools, C.hpin icaIs,
and labor requirod b- tht Contractor to perform the work as Set forth on Fxhibit "A"
and &-scribed therO n, in accordance with the attachments as listed and referenced
here i n .
TITIE OF COM- ENCEMENT AUD COMPLETION
�t Thn s>>v:�ral rr;rti-ns ,f thc: work as sot forth shell Commence on or before
D thc� AS riay (if l(1�0. and shall hp complet on or hoforc, the �+ ;•rnrking /W
day after coini!rtnc,:,o-?nt, srr`)jct hotre-vor to thp following:
(a) . Thl, n, =r sh : I 1 rr��'•: r►1,, h Olding, rnn��)letri with necessary ritilities
and facilities, av� i l,�nl;, to �lshest:) I r',�ntr,rctor on or hef( the r,r)r mirincement date.
Any del ay of viva i 1 �e1)i I i t•;• Chia l l ��:�1 ay t h-, cl)ilwioneoment date and any delay exceeding
throe Bays may, at �„s optiol nt talc--1r„)('stos ;'ontr<ictor, makr. the entire contract
void and of rr) frirtfr••r cif fey,
( h ) . I t i s ij1-lo orstood and .igroil(l hotwo in th-F� pa rt i es that i n the event that
the Asbestos C.nntractnr is do l,i--od in porf�ir•maoco by strikes, 1 ;0or disputes,
lock -outs, unavoidable casu(ilties or other causos hiyond the r:ontrnl of the Asbestos
Contractor, then the time for perfor-nance shall br• extended from day to day plus a
reasonable and additional time as may he reg1,irPd by the Asbestos Contractor to
return materials, tools, and personnel to the work places in the event that the delay
has exceeded three working da,;,s. Unrikirey days as used herein shall be from 7 A.M.
Monday to 6 P.M. Friday i ncl cisi ve.
PRE-COVIMENCEMENT InSPECTION
The Asbestos Contractor and nw,ner shall Jointly tour and inspect the
building, grounds, and work areas mating tho 0xistance, configeiration, and condition
of all property, e.luipi-iRnt, furnitur-1 and interiors including condition of tailings,
walls and floor coverings. Such notations shall he in writing and both parties shall
sign the written notations of the toijr, thereby agreeing to they conditions necessary
for the Owner's re-acceptarr; e .If tho project at tirnr! of completion, Any
post -completion itom not noted on this documcnnt shall he at the Owners expense and
shall not he c:aus(- of delay of payments of any contract prices set forth herein.
COUROL OF WORKPLACE
It is agreed and understood by the parties hereto that asbestos is generally
classified and recognized by persons knoaledyable as to its, characteristics as a
hazardous material. rurther, the transport, removal, encapsr,lation, or installation
of the material royui res due caution and ad*he-rance to rigid safety and health
procedures. Therefore, the parties agree that access to and control of all araas
where the Asbestos Contractor is to perform iin"dor this contract and during that
performance, shall be under the exclusive jeerisdiction and control of the Asbestos
Contractor, excepting therefrom only }--mc!ryency situations wh;3re the prpmi sQs are
threatened by fire, flooding, or other si tliati nn rogrei ri ny immediate action by
persons other than the Ashostos Contractor to i)rPvent loss of life or property.
The Ashpstos Contractor shall ost.ihlish proc��di,res and controls Asbestos
Contractor shall deem reasonably noce ,;nary to control and prPvont the, esra � of
asbestos materials and to contain those .. � p
_ materi a 1 s within thy. ,pork areas and areas
(�stahl i shed as romoval and transport arras. Those proced;,rcls aro mom specifically
g� set forth on Attachln►ant ". Additional to those areas shall he a set
01^ forth on Attachment _-• A Copy of those e)rocedurps shall he posted at the normal
and usual entrance~ into the- arpa or areas in which work. will be performed under this
p i
contract. Further, the cfwnor hr?rob agrees to providti a .-opy of attachmi.,nts and Of.,64-
to any other contractors, security 13ersonnel or workers not irn;ler the control of
Asbestos Contractor.
Breach of these conditions by the Owner or any ayent of the Oviner or by any
other porsnn or oryanization derforming services for the Owner shall b- a breach of
this contract, acid Shall ontitle tha Ashostns Contractor to i►,►r►(ldiatoly cease
operations withtitit fiirthor_ iahi I ity f(ir perforriance Froundpr. Tho Ashestos
Contractor shall a:ldit.innally have the o)clusive option to continue performance
hereunder after ►ch hroach -int P),rr,,!din-- throa working days has bean corrected. Any
delay occasioned by a hrnach hereunder exc�:-edi ny three days, shall gi vP tht� Asbestos
Contractor tho ri(,!it t.) th-clar- .I, 071t contract ire rlr�fault and thE!reafter take
such action as ,:ay low •,r eye, i ty.
STRI:CTIIRES
This Cr!ntract :ii:,:s not inchdo the Prectinn or rovio�val of ;any permanent
structural co►ipori ants to bijiI(Iin;;s or Incations unless specifically sot forth on
Exhibit "A", and any such oroction n;r renr.,val as riay he rf!quired by the Asbestos
Contractor in perfor►Trance hereunder shall he the sole and separate responsibility
and at the expense of the Owner. Any delay in such construction or demolition shall
caust� a day by day addition to th.-, time (if performance by the Asbestos Contractor
and if exceedi ny thraE,, -vrorl; i ny clays shall give the Asbestos Contractor the right to
declare the entire contract in def(-j:ilt.
This soction shall not amply to tho erection and removal of containment
areas, shielding, scaffolding, or any othNr temporary structure regaired by Asbestos
Contractor in the performance ► equi red under this contract.
CCI:TRACT C11AUGES
This contract is fixed both as to price and as to performanct� as set forth
on Exhibit "A" or any proposal usf�d in lieu thoroof. Addition~, dpletions or
alterations to the work to he performed requested by thra ;lamer after execution of
thi s contract sha l 1 he acco vipl i s!ie l only by writ ton ch,anya order for a price
ne��otiated by the partir�s. Ct anye orders shall he r.onsidered adds ndums to this
contract and shall modify both ►nanner and time of pprformance as well as price
hereunder.
TEMPORARY SITE FACILITIES
The Owner shall provide, at nn r-xppnse to the Ashestns Contractor, water,
heat, light, electrical power, sanitary facilities, weather protection (where
required), and secijr r ty services between the hours of 6 P.M. and 7 A.M. during
week -clays and ?4 hours per day from Friday 6 P.M. to Monday 7 A.M. Security services
for the containment area during work hours as defined herein shall be the
responsibility of Asbestos Contractor.
PAYi4ENT
Unless otherwise, specified on Exhibit "A", final dayment shall he due when
the work dr:,scribod is fuIly coriplr-ted and performed in accordance with this
contract. Completion shall occurr wh.nn work is compl?te, final inspection has taken
place and when all submissions as set torth on Attachment _� have been made by the �f�+
Asbestos Contractor to the owner.
Payment in full shall ij-zmediatc,ly h,r, due and payable thereafter, and any
amunts not paid within t n days shall draw interest at the rate of 1 1/2 % interest
t
per month on the unpaid balance from thp date payment is due.
Progress paymonts, if any, shall be in accordance with the provisions as set
forth on Exhibit "A".
CONDITION OF WORK AREA, INITIAL AND FINAL
It shall be the sole_ responsibility of the (hrner to provide, prior to the
commencement of the work by the Asbestos Contractor, accoss to all areas where work
is to be performed, free of known obstructions and hazards, and a continuing
responsibility to inforri they P,shPstas Contractor of hazIrds which come to the
knowledg,� of the Ovinor during the performance of this contract.
If the strs}.-teiro is to h, � rep-n;o'lel cad or demol i shod after performance
hereunder by the Asbost—os Conrractor, the Asbestos Contractor shall have no
obligation to rpscr')ro t10 }1rt��,� i s:.�s :)th:1r than removi ny temporary structures
associated with contaitirvAnt aid ho ards crnated by the operations of the Asbestos
Contractor. If such hazards cannot he reasonably removed, Asbestos Contractor will
mark and identify the hazards and -warn the (lamer of the location and nature of those
hazards.
If the structure is to be occupied or used after performance hereunder by
the Asbestos Contractor, the Asbestos Contractor shall be responsible for restoring
the premises to the gene-ral condition existant at start of operations, excepting
..therefrom the removal of hazardous product as set forth by this contract.
PERFORMANCE, LABOR, AND MATERIAL BONDS
Prior to commencement of performance hereunder,
Asbestos Contractor will
provide the
Owner with a copy
of a performance bond issued
by an independent bonding
company, or
in lieu thereof,
a cash bond in an amount of
not less than 1 112 times
the contract
price he,roundar.
A general performance bond shall be satisfactory
substitute
herefor provided
that such general performance
bond is not limited as to
location of
work performed.
INSURANCE
Owner shall have in full force and effect, insurance for fire, theft,
damage, or other caustiaity incurred during the course of this contract not a result
of the acts of the Asbestos Contractor or agents thereof.
Asbestos Contractor will provide evidence of insurance valid during the
course of this contract insuring against the acts of the Asbestos Contractor in the
performance hereunder. Said insurance shall include Workmans' Compensation, Public
Liability, and fire dnd extended coverage.
Each party hereto shall be considered as an additional insured party to the
insurance coverage of the other during the course of performance hereunder, and if
proceeds of insurance are paid as a result of casualty coverage, such proceeds shall
be allocated in the ratio of loss of each party.
SUB -CONTRACTORS
Asbestos Contractor shall have the right to employ the services of
sub -contractors in the performance hereunder. Any such sub -contractor employed shall
he bound by the same terms and conditions as set forth herein as binding on the
Asbestos Contractor. Asbestos Contractor will not suffer or permit liens on the
property and shall timely pay and discharge all reasonable labor, materials, and
other obligations owed by the Asbestos Contractor to sub -contractors that affect and
pertain to the work to be performed hereunder.
The Ashostos Contractor shall notify Owner of the names of sub -contractors
proposed to perform the principal portions of any work hereunder, and shall not
employ any sub -contractor to whom the Owner has reasonable objection. The Asbestos
Contractor shall not be rtg0 red to employ any sub -contractor to whom Asbestos
Contractor has reasonable objection.
CORRECTION OF WORK
The Asbestos Contractor shall correct any work that fails to conform to the
requirements of the Contract docur i-.1nts if di scovi red prior to or during final
inspection. After final inspection and acceptance by the owner, Asbestos Contractor
shall correct only slich items as fail to meet applicable regulations regarding the
handling, removal, or encapsidation of asbestos products. The provisions of this
article apply to work done by scab -contractors as well as direct employees of the
Asbestos Contractor.
ARRITRATI0H
All claims or disputes arisen; out of this Contract or the breach thereof
shall be decided by arbitration in accordance with the Construction Industry
Arbitration Rules of the American Arbitration Association then obtaining unless the
parties mutually agree otherwise. Notice of the demand for arbitration shall be
filed in writing with the other party to the Contract and with the American
Arbitration Association and shall he made within a reasonable time after the dispute
-has arisen.
The prevailing party in any arbitration had hereunder or subsequent action
by a Court of competent jurisdiction in aid thereof, shall be entitled to award of
costs and reasonable attorneys fees.
INTERPRETATION
This Contract is to be construed and interpreted. where necessary, in
accordance with the laws and regulations of the State of Colorado, and any
liabilities or damages flowing herefrom shall be determined by reference thereto.
Any provision hereto shall he severable if required for interpretation or
if unenforceable by law, without affecting or altering the remainder hereunder or
the liabilities or benefits herein.
This agr ment executed the day
wnor
b .
7q� 5 '
tit I e: 4
and date first above written.
ASBESCO, INC., A Colorado Corporation
Asbestos Contractor
by:
title:
1
DEFINITIONS
The following list includes those words or phrases within the contract to
which this docur,rent is attached which are unique or common to the asbestos removal,,
control, and abatement industry. The list is not intended to be all inclusive nor is
it intended to exclude stich definitions as may be reasonably necessary or proper for
interpretation of the contract. Any item contained on this list shall, however, take
precedence for purposes of definition over any word or phrase which might be
otherwise defined.
Abatement
The processes or NrocodiiroS used to docrease or eliminate the release of fibers
from materials rorita i ni ng js,)f,.stos to the surrounding atrrosphere or structures. This
definition sha I 1 i!1 1 ,)rocedtjres for the Pnca-isu 1 ati on , containment, removal,
and disposal of asbestos containiny ;:raterials at or from affected locations.
Airlock
A device, system or structure allowing ingress or egress to a Containment area
without causing the migration of asbestos outside the containment area. May be
designated as f�quipmont or personnel and typically consists of two or more curtained
entries separated by an enclosed transition space.
Air Monitoring
The process of sarrrpl ing the air at a location for the presence of airborne
particulate matter, specifically as used herein for the presence of asbestos fibers.
Amended Water
Water containing one or more surfactants.
Asbestos Contractor
The person, company or ether legal entity having the right and duty by written
agreement executed by both that entity and the building owner or General Contractor
to contain, reinovo, encapsulate, abate, and/or dispose of asbestos products. Where
the agreement is executed by a General Contractor, the entity providing asbestos
control services may also be referred as the Asbestos Sub -Contractor or
Sub -Contractor.
Authorized Visitor
Those persons who have been designated in writing by the General Contractor,
Building Owner, or the Asbestos Removal Contractor as having right of access to
areas in which asbestos abatement procedures are in progress.
Building Owner
The owner of record of the property and improvements upon or within which the
asbestos is to be removed. This definition shall include those persons who have been
designated in writing by the owner to act as agents for said owner.
Containment
The processes, procedures and techniques of isolating materials or surfaces
containing asbestos contamination for the purpose of preventing the further spread
of such contarination to ajoining or surrounding areas.
Containment Area
A temporary work location Pstahlished rising suitable procedures and materials to
prevent the migration of asbestos or asbestos contaminated materials to ajacent or
surrounding locations.
if I
Decontamination Area
An enclosed room or area connocte:i to the containment area by one or more airlocks
used to remove ashoctos coma : atiori frow personnel and equipment prior to movement
to .incontrol 1 ed areas.
Disposal
The transportation of encapsulated asbestos or asbestos contaminated materials from
the work site to a disposal site.
Disposal Site
An established area or
local, state, or ft--doral
hazardous, or controlled
location approvild, monitored and designated by appropriate
authorities and used for the permanent locating of toxic,
substances.
Encapsulation
The processes or procedures wherchy materials or substances containing asbestos are
impregnated, coated, covered or surrounded by other materials or substances designed
and intended to prevent the ascape or migration of asbestos from the material so
treated.
General Contractor
The person, company or other legal entity having the right and duty by written
agreement executed by both that entity and the building owner to construct new
improvPments or demolish, re -model or modify existing structures on real property.
If the nature of the work to be performed consists exclusively of asbestos related
activities, the Asbestos Contractor may also be referred to as the General
Contractor.
HEPA Equipment
High efficiency particulate absolute vacuum devices containing a filter system for
retaining asbestos fihers greater than 0.3 microns at 99.971. reliability.
HEPA Filter
A high efficiency partic0 ate absolute device normally attached to HEPA equipment
used to and capable of trapping and retaining asbostoes fibers having a length
greater than 0.3 microns in length at 99.99% reliability.
Negative Pressure System
A device or groupin, of related devices used to maintain an atmospheric pressure
diffe-intial hetween a containment area or decontamination area and ambient air such
that the containment area or decontamination area has an atmospheric pressure less
than ambient pressure.
Regulations
The most recently published issues of all written and published directives,
procedures, legislative acts (including revisions and amendments, and other
documents established for the purpose of setting minimuvj standards for the use,
control, application, removal and storage of dangerous, hazardous, toxic or
controlled substances. As used Iertiin, the definition shall include, at a minimum,
the following:
A. Title 29, CH Svctions Hie .1001 (Asbestos), 1910.134 (Respiratory
Protection) , and 1910.145 (Si gnaye) .
R. Title 40 UR, Part 61, Subparts A and B (National Emmission Standards for
Hazardous Air Pollutants.)
C. ANSI Z.9.2-71 Fund-imental s of Local Exhaust Ventilation Systeins
f1, Applicahl., state ;,nd local codes and ordinances as applied to asbestos.
Removal
The processes, procedures and methods for relocating asbestos from surfaces,
materials and areas to enc.apst,lation devices.
Sub -Contractor
The person, company or ether legal entity having the right and duty by written
agreement execi,ted by both that entity and the Asbestos contractor to provide
asbestos control services.
Surfactant
An additive chei:i i ca 1 ajen t used to increase the viet t i n and penetrant ability of a
fluid.
Worker Protective System
The articles of clothin;, �,arrionts and protectiv,� devices i,sed to prevent a person
present in a containment or docnntami nati on area from being directly exposed to
asbestos fibers, either by body contact or by inhalin�-j or ingesting such fibers. A
complete system would consist, at a minimum, of disposable outer garr'.lents,
protective foot coverinjs, disposable gloves, head covering, and a respirator
covering both nose and mouth. Any person actively enyaged in abatement would also
require eye protection.
llftw r.+ '"W�%
CONTAINMENT AREA CONTROL
No building owner, General Contractor, Sub -contractor,
authorized visitor or any other person shall enter or attempt to enter
a containment or de -contamination area, unless, prior to such entry,
that person has the written ;permission of the Asbestos Contractor or
does so under a general authorization provided for under contractual
agreement between the building oarner, General Contractor, or
Sub -Contractor. Any person violating this provision shall be
immediately subject to being detained for action by law enforcement
authorities or ejected from the premises. Regardless of prior
permission, such entry shall be only during hours and ender such other
conditions as vstah1ish.�d by the contract of which this is a part.
Thi s sec t i on sha 1 1 not: app 1 y to personnel ent•r1ri ny the con to i n;nE!nt or
de -contamination area for emergencZ pruposes sacs as th* JPVtft1®tL ®t
theft, fire or damage to the ,premises with the implied authority to so
enter.
All persons entecriag itreas designated as containment or
de -contamination areas, except as set forth above for emergency
purposes, shall be c�gliipped with grid using a worker protective system,
shall enter and exit only through designated air locks, and shall upon
exit from the area, use available abatement equipment, facilities and
procedures to prevent the migration of asbestos fibers from the
containment• or de -contamination areas. Further, upon exit, all
disposable articles of outer clothing including respirator filters
shall be placed in designated containers. No article of clothiny, item
of equipment, sample or any other moveable object shall be removed
from the containment or de -contamination area unless it shall have
first been do -contaminated or vorified by the Asbestos Contractor or
authorized agont as being free of asbestos contamination.
When attached to the contract of which this is a part, the
document entitled 11 Work Area Procedures" shall supplement and be an
addition to this section.
/np
- 1 -
"Wavo %.�1
CODES,REGULATIONS, ORDINANCES
The following codes, regulations and ordinances are applicable to
performance under the contract to which this is attached. The following list is not
all inclusive, and additional regulations may apply in the local jurisdiction in
which the work is to be performed.
1. Title 29, CFR, Section 1910.1001 (Asbestos)
2. Title 2.9, CFR, Section 1910.134 (Re-spiratory Protection)
3. Title 29, CFR, Section 1910.145 (Signa;;e)
4. Title• 41, MI., Part Al, S-ih-ijarts A and B (National Emission Standards for
Hazardous Air Po I l otants )
5. A^1SI 7..9.2. (1971) Funrlai!ivntals of Local Exhaust Ventilation Systems.
6. EPA Publication 560/5-83-002 (Guidance for Controlling Friable
Asbestos -Containing Materials in Buildings)
7. ANSI Z-30.2.-80 Respirator Control Procedures
8. EPA, OSHA, N10SH regulations and procedures as they apply to control,
removal, and disposal of hazardous materials.
ESTABLISHING THE CONTAINMENT AREA
The following procedures are intended to be the general procedures for
establishing and maintaining the containment area. They are not all-inclusive and
additional procedures i;tay be required on the specific project to which this
attachment pertains. In all cases where additional precautions are required, the
more stringent procedures shall in all cases apply.
1. Prior to commencing work, the area or areas to be established as containment
areas shall be isolated and completi!ly sealf�d off from surrounding areas. Doors
which will not bo requ i red in thp course of abatement shall he sealed in such a
manner that thoy will he available only for emergency purposes. All air conditioning
opcnin s shall be covorod with a non -permeable covering and taped. All utility
outlets which might por�-ii t the nii crati on of air will he tot,tporari ly sealed. All
other openi n(;s st,ch as corridors, (i.)or►•rays, skylights, dticts, grills, diffusers and
any other penetrations shill al s:) btu sealed temporarily to establish the containment
area .
2. Movable objects shall be either removed from the area after determining they
are not asbestos contaminated or covered with non -permeable coverings and taped.
Non -movable objects which will remain in the area after final clean -tip shall be
covered or otherwise protected to prevent asbestos contamination from the abatement
procedures.
3. The containment area shall he cleaned using HEPA vacuum equipment or
suitable wet cleaning methods. No procedure shall be used for this pre -cleaning
which will raise dust which ;night migrate outside the containment area. All
equipment used for this process shall be equipped with suitable IiEPA filters.
4. Floor and wall surfaces shall then be covered with a non -permeable covering
such as 6 mil plastic sheeting. The floor covering shall extend at least 12. inches
up the walls and wall coverings shall extend to the floor level. All lap joints
shall he sealed or taped to prevent tniyrati011 of contaminants behind the
non -permeable barriers.
5. Airlocks and passages for equipment and materials are then to be
established. In all casos, access between contaminated and non -contaminated rooms
shall he through an air -lock and access between roosts within the containment area
shall be through a three curtained door -way.
6. If separate areas of the building are to remain occut)ied or otherwise in
use, they must be separated from the containment area by both air -tight barriers and
by vandal barriers where necessary to prevent breach of the containment area.
7. All barriers and non-perrTteable coverings are to be periodically inspected
for breach or daanage. Upon discovery of such damage or breach, it shall be
inirtediately repaired and all exposed surfaces are to be considered as contaminated
until monitored or cleaned using suitable trocedures.
S. Once established, the costa i rn lent area is to he ►rtai ntai ned at negative air
pressure d►jrinU all tirtos that personnel are present or work is t,rtderway in the
area. There shall be no requiroiiont to Maintain negative air pressure during
nort-work periods, provided that adoy-iate security is used to prevent non -authorized
persons f rota entori ny the costa i ni:r�nt area and no activity is underway which might
cause migration of asbostos fibers,
ASBESTOS REMOVAL PROCEDURES
The fallowing procedures art? to he considered as the minimum required
procedures for control, removal and containmi-.�nt of asbestos contaminated surfaces,
materials and objects. These procedures are not intended to be all-inclusive and
additional procedures may he required glue to the nature of the work to be performed.
In all cases, where these procedures are ,modified, the more stringent procedure
shall control. Modifications of these procedures shall be the exclusive right of the
Asbestos Contractor and shall be done in accordance with existing EPA, OSHA, and
NIOSH rules, re;tjlations and advisories relatinc; to the abatement and control of
hazardous materials. Authorization for st,c-h modification from any other person shall
not be of fecti v,� trnl ess reasonably o2cessary for the ii used i ate protection of persons
or property frog, irtminont risk of 1»dil, injury or destruction.
1. Al l b1;1 K rr*,.rrlval Of asbestos containing ,materials shall be done by
immediately placing st,ch object,, in non-permaeable containers having suitable
strenyht to prevent penotrat i ore by objects placed within the,►i. All such containers
shall be suitably ,narked or labeled as containing asbestos products.
2. All
surfaces from
which
ashestos has bean removed or surfaces which may be
contaminated
appropriate,
with asbestos
vacuumed with
shall
HEPA
either be wet wipes with amended water or where
cloths, mop
heads, etc,
used
vacuum equipment. All wiping materials, disposable
in the cleaning
non -permeable
container suitably
process shall be stored in a
marked.
3. All waste water created from wet wiping and wtq stripping and all shower
water waste shall be considered contaminated. No such water shall be disposed of
until it has been filtered or placed in suitable containers for disposal at approved
sites.
4. Before co(lirllPrlclrlj the removal of dsbestos materials, the surfaces shall be
sprayed with amended water using airless spray eyuipaint or compressed air at low
pressure capable of providing a ",,list" application to prevent airborne migration of
asbestos fibers. The work surface sh;)ul�i be kept continuously wet during the work
process to nrinirmize fiber dispersion.
5. .Untreated surfaces of ashestos r,ldterial left in place shall be enca ululated
in a non -permeable material or shall be enclosed behind permanent air ti ht
barriers. Such surfaces shall he ,narked and labeled as containing asbestos rodu y
p cts.
6. When an ashestos waste container has been filled, it shall be sealed and
checked for proper rnarkin;s. The outer surfaces shall be wet sponge cleaned and
immediately removed to the decontaminaiton and disposal area. Where appropriate,,
waste containers shall be evacuated before final sealing using HEPA equipment so
that the interior of the container is at negative pressure after final sealing.
9
7. After all asbestos material has been removed and bagged or sealed and
identified, the containment area will be HEPA vacuumed and wet wiped. After the
sealed containers have been removed, the room shall be completed cleaned and/or wet
wiped and an air sample taken in accordance with test ing/moni•toring procedures. If
found to be free of asbestos contaminants, the room will be sealed and marked as
non -access area until all areas within the containment area are free of asbestos
contamination.
ABATEMENT OF CONTAMINATED SOILS
Abatement of asbestos contaminants within soil generally consists of three
procedures; (a) excavation of the irmrrediate surface of the soil, (b) vacuuming of
the soil sr,rface when contamination is only on the surface, and (c) solidification
of the soil surface to ;prevent migration of asbestos fibers.
The following procedures are to be used when abatement work is to proceed
where asbestos products have contaminated soil material. The procedures as outlined
are alternative and completion of each procedrrrP is not always required. The choice
of procedures shall be the exclusive decision of the Asbestos Contractor, and any
work performed shall be in addition to the normal procedures set forth in the
contract to which this is attached. Unless specifically set forth on the description
of work to he pElrforured or unless specifically set forth on the bid proposal, the
cost of soil ahatew:r nt shall be dotLrriined by separate hid and acceptance. Such
acceptance shall consti tutti a ad. en. -him or chari to order to the base contract and
shall increase the ovi ral l ,,rice (accordingly.
1. Excavation of soil surfaces is to be used when pre -work inspection and soil
sampling indicates that contamination extends to a depth which would make vacuuming
ineffective. No excavation shall take place unless sufficient wetting of the soil
has taken place to minimize migration of asbestos fibers. .
� Generally, the wetting
..procedures shall fallow those used in the earth moving trade for air pollution
abatement, but in no case shall excavation procedures continue where soil moisture
is less than H% by weight. Further, amended water "misting" shall be used in the
inirediate vicinity of the excavation activities at all times that soil is being
removed and prepared for disposal.
Depth of soil removal shall be pre -determined by inspection and sampling. In
the event that progress ins;iections and ongoing sampling indicates that additional
depths of excavation arP required, the contract price shall be increased in direct
relationship to vulm-le rerrovpd.
Soil removed for disposal shall not he transported beyond the immediate
vicinity of the excavation unless the contaminated soil is first placed in sealed
containers, suitably marked and the outer surfaces de -contaminated before transport.
If permitted by current EPA, NIOSH, and DOT regulations, the soil may be transported
in bulk containers, but in no case shall the contaminated soil be transported in
open containers.
2. Vacuuming of soil to remove contaminated surface soil may be utilized where
appropriate. Vacuum equipment must be HEPA filtered and all filters shall be
disposed of after use in accordance with normal procedures for such disposal. Depth
of removal shall be determined by normal sampling p g procedures, and in the event that
removal exceeds 1 inch, the removal shall thereafter he deemed as excavation and the
contract price adjusted accordin(,-ly. Soil removed shall be contained for disposal in
accordance with normal procedured for disposal of contaminated waste materials.
3. Where excavation or vacurmri ng is cleemed in -appropriate, soil shall be
subjected to a combined surface solidification and stabilization procedure. That
procedure shall be similar to concrete surfacing except that arnanded water "misting"
shall be used in addition to concrete procedures while work is in progress. Surface
coating procedures such as "asphalt Pavirly shall generally not be appropriate
unless the surface is unlikely to !)e srrbjQctr!d to loads which aright reasonal ly break
the coatis j.
4. Regardless of the soil abatemont procedure used, no asbestos contaminated
` mat`erial shall remain in the area of operations which might reasonably cause
subsequent release into the atmosphere of asbestos particles in excess of EPA
guidelines.
5. At completion of soil abatements operations, the site shall be final sampled
to assure compliance with such EPA guidelines.
AIR AND SURFACE TESTING AND MONITORING
A. AIR SAMPLING
Air sawpliny shall be divided into three phases and shall be further divided
into three area sampling requirements. The three ;phases are:
(a) Initial Pre -Contract Conditions,
(b) Progress S.imp l i ny,
and (r,) Final Inspection
The throe sitiili}llnu regijir.--,-:ants are:
(i) outsido tho -irea ,
(ii) iutside th,.� buildin;,
and (i i i) inside the containment area.
All sampling except as otherwise noted shall be determined by a minimum
sample size of 960 liters (u hour TIWA) at sea level adjusted to the standard
pressure altitude of the work site. Daily samples will be taken while work is in
progress in accordance with al.plicable regulations including but not limited to OSHA
requirements for ceiling concentration (Personnel) and 8 hour tirir. weighted avi�raye
for work area exposure level.
Air sa pl my shall also be acc:oindl i shed while abatement work is in progress
by attaching a savilil i rig device to one or more workers. "Jot less than one sample
shall be taken of Q.(, liters per cc for i)ne hour.
A. 0) Initial Pre -Contract Condition%
A singlo air sai-iple shall he taken by the Asbestos Contractor before
commencing work (a) outside the building or buildinys, (b) inside each building but
outside the work area, and (c_) at the work area. These samples shall be Asbestos
Contractors samples for historical and comparison purposes and shall not be part of
final inspection roiluirenients.
A.(?.) Progress sampling
Progress sampl i ny shall be as follows:
(i) outside the containment area- one sample daily (Minir,iurn)
(ii) within the containment area- as required by the Asbestos Contractor
(i i i) worker sampling- as reg0 red by current OSHA regi,i rPments and by the
Asbestos Contractor.
A.0) Final Inspection Satiiplinu
Final inspection saoi-J my shall be submitted as a part of the over-all final
insp?ction of the job, rind shall c1 resist of:
(i) an ambient air sample taken _outside each cirffected building,
f
(ii) a sample taken within the containment area,
and ( i i i ) a sa^Iple taken within the bt,i1diny Nit outside the containment area.
Work shall be deemed complete cihen the final inspection saripl i nq indicates
that interior sa-npl a results are equal to or less than exterior sample results and
the average of the l:�st three consecutive air tests yield a res+ilt of equal to or
lvss than 0.02 asbestos fihers per cubic centimeter of air samliled.
TOOLS AND EQUIPi4EIlT
The following is a partial list of the tools and Pilo pr;ient required for
performance under the contract to which this doctr-:rent is attached. It is not
intended to be al 1-i ncl usi vo and additional tools may br, required. Where rni nimum
reyui rei-iients are set forth for specific tools and equi l-Aiient , those requirements
shall be mandatory both for the listed equipment as well as any alternative or
substitute equipment which may be used in derforrrrance of the contract.
All Power o-.fu i pr v,nt shall r ioet this api l i cabl a standards set by A14S I , III,
ASTH, or MIL spoci fi c:ati (iris and shall be kept in good repair and in operating
condir.ioi-i.
CPrLai n tools &..rid .*,4ui f Bent to ')e r,serd in performance of the
contract are of
spr'cial
desi jn ,and pt-rf!-)r,-,lance :an.] aro propr'ic-tary to
the Asbestos
Contractor. The
Asbestos
Contractor ►J 11 certify that those items
of equipment
mNet or exceed
applicable
standart.+s for i tams pprforrii n� tho sar;ir,
functi.an, but
shall not be
reyui rod
to revoal the ;exact perforr-;:rnc►� or ,f
operation of
those iteris.
1. hand tools including cleaning equi,wient.
2. Airless or low pressure 1 i.lui d power operated spray oqui ps:rent .
�. Scaffol(Iin-j
4. Communication equipment suitable for efficient inter -room communications.
5. Environr:iental Control Equidvient, including but not limited to exhaust
ventilation and dust collection, used for reduction or elimination of airborne
asbestos fibers. Such equi pvient shai 1 be NEPA rni nir•ir.rrn designed, constructers,
installed and m�ii ntai ned ill accordance with ANSI Z9-2-1971 as airrencded . Area exhaust
units shall be ut i l i zed and verrtpd to di schargo outs i dt, the building and provide
negative pressure in the contai rs„iont are: for the duration of the work to be
performed. The (filtered) negative air systetil shall provide pressure differential
frow intake side 6f the prim,iry filter to the exhaust side of the NEPA filter. The
filter system( shall be capable of removing 99.99% of all airborne asbestos fibers
greater than 5 microns in size as tested at 0.02 cubic centimeters of air at the
outlet filter.
5. Personnel respiratory protection equipment meeting the standards of 29CFR
1910.1001. All such equipiliant shall have replaceable and disposable filter systems
capable of accepting both particulate and chemical abatement filters unless the
equipment is generally knovrn as "supplied air" deriving its atmosphere either from
connected external sources or fro,n "bottled" air.
7. Personnel eye and head protection devices where the work environment
reasonably requires such protection.
8. Protective frill holy clothing consisting at a minimum Of full boa coveralls, h; adgear, and four covi�ri nys. Such equipment may consist of both
disposable and non-disj,osablc� articles.
CLEAN UP AND DISPOSAL
A. Clean-up
Vi si hl e accunul ati ons c=f asbestos material and debris shall not be preanitted
during the removal operations. All contaminated materials shall be placed in
suitable contain:irent devices and when those devices are filled, they shall be
sealed, the outer s!rrfacNs de -contaminated, and reniuved to the de -contamination area
for placement in disposal containers.
Disposal containers shall not hip permitted to accu!cruIatP. in the
de -contamination area. As such containors are generated, they shall be sealed, the
outer surfaces dt:*,-ronta,iinatvd and rrarkekl in accorridnco with existing regulations,
and thzy shall 5o r.>>*,:av,,d to ti-ml)(irary stora�jP pendinij trans;)()rt to permanent
disposal sites.
After all i,00s;is pro :,r: as within the containment area have been
de-contani nated and al I vi i hl asht�stos Pit-1-or removed or Pncaps0 ated, the floor
and wall cuverin;s sh,_ill be reiiioved. Co verinus on doors, windows, vents, etc. shall
not he removed at this tim,, .
All surfaces within the contai n;!ient area shall then he cleaned with water
-and HEPA vacuucr equipment as appropriate. A detailed visual inspection shall be
performt-,d by the Asbestos Contractor for the prPsence of visible asbestos products
or rnateri al s. If asbestos is found to be present, it will be revioved or encapsulated
and the area a ,jai n cleaned and inspected. If no visible ashostos contamination is
found, the area will be air monitored and sampled for asbestos fibers. A sampling
test yielding a resu 1 t greater than 0.0? fibers per cubic centimeter of air shall
cause tha entire containiriont area to he wet cleaned again and such sucessive
clednint s shall continua& until air sample results yield an asbestos fiber count of
equal to or 1^ss than 0.02 fibers per cubic centimeter of air sampled.
When both visual inspection and containment area air samples indicate the
containment area is free of asbestos fibers, the "final" containment area and
outside "amMent" air sawples shall be taken and compared. When those tests are in
accordance with air sar;ipl i ng and monitor standards set forth el set•rhere, the removal ,
containment and encapsulation portions of the contract shall be deemed complete.
Removal of temporary barriers, containment area structures, equipment, and all
remaining barriers between the co�ntainurent area and other areas within the building
or buildings shill proceed. All such materials removed shall either be wet
do -contaminated or disclosed of as contaminated waste. Any residual (Just or debris
shall also be disposed of as contaminated waste.
B. Disposal
HO contar:rinated waste shall he removed from the containment area unless and
until it has been placed in irnijernreablP containers, suitably marked and the outer
surfaces de -contaminated.
All irrpermeahle containers shall, in turn, he placed in disposal
devices (ie, r:ietal drums), and tho outer surfaces de -contaminated and
suitably marked. As sufficient Filwibers of such disposal containers accuviulate for
efficient transport, they shall he removed and transported to an EPA approved
disposal site. The contt-jinors shell he both air and water-tiyht and during transport
shall riot he unreasonably exPosed to risk of dai.-rag(., theft or vandalism.
An asbestos disposal fora previously approved by the Asbestos Contractor
.P_
yea u04 .�ole,�ado �,l ls [�socis La ue ua�.�udsue.�� a�, sa�ln��;�l �esc�ds �p �u �Cuan � Sap
N y� P ,� y�oy 4 Pa:IaLduiu:) aq LLuys
FINAL INSPECTION AND ACCEPTANCE
A�. Final Inspection
Prior to requestinj a final inspection tour, the Asbestos Contractor will:
(a) . re-establish all moveable objects to their original positions as noted
on the pre-comvmncement tour,
(b) . remove and dispose of 11VAC filters as contaminated waste.,
(c) . rec+rt i v:lt;- h!: i 1 di ny utility systoms as directed by the Owner and as
requi rod by thri
(d) . Co{:{,�l i't►? :Ili j' I1� llr+r r!:) �(I t l on s cont d i ro-d on thepr,�-(:OI1�I11�?ncelllpnt tour
doctivi `nt .
The to r(,;!t.r<<: for ind ,Iwner wi 11 then jr)int I tour th,� bui lding,
grounds and work ar;�,l, notin�j any itoi!is contained on the pre-cormiencement tour
requi rr,d h;-fora ri*,-accol, tancn ry the owner, r)111y i ter -is contained on the
pre -commencement toter are required to be completed by Asbestos !'ontractor before the
final physical inspection shall be deemed corr,)lote.
B. ACCEPTANCE
When the final physical insliection is complete and the Asbestos Contractor
has blade all subrli ttal s contained on the documcint entitled "Submittals Attachment",
the Owner shall have 413 houri to object in writin j to any itom the Oviner reasonably
believes does not conforrl to the contract or performance thereunder. Failure to
provide such -written notice shall constitute waiver of any such discrepancies and
acceptance of the project and contract performance.
` SUBMITTALS
6'
The fol 1 owi nay list shall constitute all documents reclu i rPd to he submitted
by Asbestos Contractor to Owner pursuant to the contract to which this is attached.
Exact photocopies of those documents shall be deemed as corral i ance.
1. Federal (EPA), State and local permits ( where applicable).
2. Landfill Operators Pormi t
3. Disposal Certi f i : att,
4. F,r idl OP-0 .i^-j* C:if1-ron t r actors Release for;-;-,,
5. Area i1n i i r. ".?! 111 i rtti PE'S;il t$.
G. Incu r;ticc "ort.ific,-jto.
7. Final Inskwc.tion
EXHIBIT A Proposal _ , , :_ ° `�
Proposal No.
p 219 6
FROM ASBESCO INC. ,:' -
Sheet No. 1
1759 VAN B UREN WAY
AURORA, COLO. 80011 tt f
Date Sept. 28, 19
PHONE: 361-6667
�ZZ-�J/GG
Proposal Submitted To
Work To Be Performed At
Name Eagle County Goyt
Street 550 Broadway
Street 550 Br W
City Eagle State Co.
City Eagle
Date of Plans
Architect
State Colorado
Telephone Number 1-328-2311
We hereby propose to furnish all the materials and perform all the labor necessary for the completion of
Remove and dispose of asbestos from pipes and joints asspecified,
All work to be done in compliance with E.P.A. O.S.H.A and Colorado
clean air re 'ulations. All work to be done by qualified persons with
Asbesco, Inc.'All lab reports and analysis to be done by Hager a ora orl
Inc. All monitoring to be done by independent monitoring company.
A copy of these reports will be given to the above named agencies,
along with a copy to the owner and contractor.
All material is guaranteed to be as specified, and the above work to be performed in accordance with the drawings
and specifications submitted for above work and completed in a substantial workmanlike manner for the sum of
Two Thousand Six Hundred and no/100---------------------Dollars ($ 2, 600.00 �.
with payments to be made as follows:
Net 15 days upon completion
Completion being when lab reports are delivered.
Any alteration or deviation from above specifications involving extra costs, will be executed only upon written orders, and will
become an extra charge over and above the estimate. All agreements contingent upon strikes, accidents or delays beyond our
control. Owner to carry fire, tornado and other necessary insurance upon above work. Workmen's Compensation and Public
Liability Insurance on above work to be taken out by Asbesco, Inc.
Respectfully submitted Asbesco, Inc.
Per
Note —This proposal may be withdrawn by us if not accepted within 30 days
ACCEPTANCE OF PROPOSAL
The above prices, specifications and conditions are satisfactory and are hereby accepted. You are authorized to do the work as
specified. Payment will be made as outlined above.
Accepted Signature
Date Signature
s,
TOPS FORM 3450 0 LITHO IN U. S. A.
REAL PROPERTY DESCRIPTION
Exhibit B
1. Remove and dispose of asbestos from pipes
and joints in the McDonald Building boiler
room and coal bin. Located at 550 Broadway,
Eagle, Colorado.
2. Remove and dispose of asbestos from pipes
and joints in the McDonald Building gym,
gym stage, and locker rooms. Located at
550 Broadway, Eagle, Colorado.
�J73% 'tr
�}�j�,� i f i' �'+M. 4L '�►(� �, !' 1 " I 1 - ( Y T � �rT f"'-�. ';.l- ^ -!�'��• -� y �'� �
Y. � f: _�� 1.1 j ..,.1. T ,yam! . ��y� • h � •.. f�p..I f J ;,,;�,,
- - - G.• 1:1 r y • . � I I N .. ate. r�u - �'��i .. Y i E . � ♦ � . r r ..t'ir(u..� ��>�1w,-iT:J• � Tr.: s�si�ii' 7 :•'-�":'42�
A-Mf AND--AUEIIII.SS OF AGENCY
Walker Garrott Agency
750 Insurance Exchange Bldg •
Denver, Colorado 80202
COMPANIES
AFFORDING COVERAGES
COMPANY
LETTER A
United States Fidelity &Guar
i,(JMPANY
LET -TER
B
_
183
LAME AND ADURESS OF INSURED
COMPANY
LETTER
+ i
Thomas B utts
DBA Asbesco
COMPANY
LE TTFR
Dj'i
" `� •!
0.0MPANY
LErrER
-► „ ,;;;►a �:`
1759 Van Buren Way
Aurnrn , r`nlorado-8U-11 _
This is to Pertfy that I • f ; I d h
I po Ides o Insurance Iste bctow awe been is.,,--u to the ;nsurt-a •'erne:d above and are in force at this time Notwithstanding any requirement, term or condition
of any contract or other document with respect to wnicn this certificate may t e ,sb. LJ or may pertain, the insurance afforded by the policies described herein is subject to all the
terms, exclusions and conditioris of such put.cics.
UMPANY
Lf iTER
TYPE OF INSUI<AN� t
_-_- - -- - -� _
GENERAL LIABILITY
ruLu f ht:'.:r
_ _-- _ --- . -- _-•
POLICY
I X11HAIION DATE
__
Limits of Liabilityin
Thousands
EACH
OCCURRENCE
AGGREGATE
A
(�
9 COMPREHEN`AVL 1 UKbt
ifl)UtLY INJURY
$
$
aPREMI:,LS- LIPLRAI IUNS
EXPLOSION AND COLLAPSE
CIP 010351286
6 / 1 / 85
PROPERTY DAMAGE
$
_
HAZARD
UNOLRGROUND HAIARO
PRODUCTS COMPI LIiI;
OPERATIONS HAIARU
lUNINACIUAL IN'.UI?ANLL
RROAn I ORM PRUPFRI Y
- VAMAut
BUDiI Y INJURY AND
PROPERTY DAMAGE
COMBINED
S 500,
s 500,
INDEPINULNT CONTRACTORS
PERSONAL INJURY
s 5000
PERSONAL INJURY
A
AUTOMOBILE LIABILITY
COMPREHENSIVE. FORM
r
l�T O rYNL U
IN HIf<i U
Cxl NJN riWNf 0
BAP 024818948
6 / 1 / 8 5,
UOUILY INJURY
IEAI;H PERSON)
BODILY INJURY
(EACH ACCIDENT)
$
$
•� +'
PHOPI RTY i)AMAGi
E]01%, 'Y INJURY ANU
PkOPLRI Y DAMAGE
$ 500,
EXCESS LIABILITY
(.0mili I I)
— -
-
A
C� UMbRELLA FORM
O rtif R I HAN UMBRELLA
p p
CEP 03018080
6/1/85
6001LY INJURY AND
PROPERTY DAMAGE s 1, 000, 11,000,
FUHM
('OMBINEU
-- s v.;;.��*rs?• Y'
STATUTORY !:, `• I
-..
P $
11ACNACCIDENTI
WORKERS' COMPENSATION
and
EMPLOYERS' LIABILITY
_
13"17 (State)
6 1 8 5
OTHER
ISCRIPTIUN OF OPERA TIONS1LOCAIIONSrvEHICLES
Cancellation: Should any of the above described in)tic:le, be Cancelled betore the expiration date thereof. the issuing; com-
pany will endeavor to ty JII (l,Ji3 Wrlttr_n noUcc: t;.) the below named certificate holder, but fallure to
mail such notice shall Inipose riu Ot,II,;,jtiun or liability of at:y hind upon the company.
NAME ANU ADURESS UI CERI IF ICA I L HUt UI H - �—
TO WHOM IT MAY CONCERN
DATE ISSUED 5/24/84
AUTHURILLU ItEPFtFSI.NIAIIVE
