No preview available
HomeMy WebLinkAboutC13-260 ColWest Roofing and Water Proofing Company AgreementPRECONSTRUCTION AND CONSTRUCTION AGREEMENT FOR THE EAGLE COUNTY BUILDING ROOF REPLACEMENT THIS AGREEMENT is made this 27th day of August, 2013, by and between Eagle County, Colorado, acting by and through its Board of County Commissioners ("County") and ColWest Roofing and Water Proofing Company, a company organized and existing by virtue of the laws of the State of Colorado (hereinafter referred to as "ColWest", "CM"or"Contractor"). WHEREAS, the County intends to design and construct a Roof Replacement for the Slate Roof and integrate a photovoltaic system into the new roof on the Eagle County Building in Eagle, Colorado ("the Project") WHEREAS, the Architect for the Project is Menendez Architects, P.C., 715 W. Main Street, Suite 104, Aspen, Colorado 81611 ("Architect"); and WHEREAS, the County seeks professional preconstruction services to facilitate and assist with the design of the Project and final construction services to complete the Project as designed; and WHEREAS, Contractor represents to the County that it is authorized to do business in the state of Colorado, and that it has, by virtue of its capabilities of budgeting, cost estimating, management, and personnel: the required technical and professional expertise to perform the scope of Work set forth in Section 2 hereunder. NOW THEREFORE, the County and Contractor, for the consideration hereinafter set forth, agree as follows: 1. Definitions 1.1.Agreement" or "Contract" means this written agreement. 1. 2. "Architect" means Menendez Architects, P.C., or such other professional architect, or group or association or professional corporation of such approved professional architects, engineers and consultants, who have contracted with the County to accomplish the architectural and engineering services necessary to the Work. 1.3.Change Order" means a written order to the Contractor signed by the Board of County Commissioners or the Project Manager and the Contractor, issued after the execution of this Agreement, authorizing a change in the Work, the method or manner of performance, or an adjustment in the Guaranteed Maximum Price, Preconstruction Services, Construction Services, or the Contract Time. 1.4. "CM"means Construction Manager/Contractor 1.5.Colorado Labor" means as provided in C.R.S. §8-17-101 et seq. as amended. 1.6.Completion Date" means the first date when all of the following have occurred: the date that the Architect and Project Manager have certified that construction is completed in accordance with the Contract Documents, the local jurisdiction has issued a Certificate of Occupancy, and the date the County can fully occupy or utilize the Work for the purpose for which it is intended. 1.7.Construction Documents" means the drawings and specifications that set forth in detail requirements for the construction of the Project. "100% Construction Documents"means 100% Design Documents with further detailed drawings and sections for constructability and written specifications for 100% ability to construct the project. 1.8.Contingency"means the set percentage of the construction contract amount budgeted for unforeseen emergencies or design shortfalls identified after the construction project commences. 1.9.Contract Documents" means this Agreement, Amendments to this Agreement, Conditions of the Contract(General, Supplementary and other Conditions), Drawings, Specifications, Notices to Proceed, Change Orders, Addenda to the RFP issued prior to execution of this Agreement, if any,. and other documents as identified in Section 12 of this Agreement. 1.10. "Cost"means the total cost of labor, materials, provisions, supplies, fees, tests, expenses, bonds, equipment rentals, equipment purchases, insurance, supervision, engineering, clerical, and accounting services, the value of the use of equipment, and reasonable estimates of other administrative costs which may be reasonably apportioned to this Project to complete it in accordance with this Contract. 1.11. "Day" means calendar day unless specifically designated otherwise. 1.12. "Design Development" means the phase in which the Architect and other consultants prepare the design development documents, from the approved schematic design, for submission to the County for its approval. 1.13. "Design Documents"means the drawings and other documents that fix and describe the size and character of the entire project as to architectural, structural, mechanical, and electrical systems, materials and such other elements of the Project as may be appropriate. "100% Design Documents"means Design Documents that include grading, drainage, utility, irrigation, roadways, field lighting,building architectural, structural,mechanical, electrical, plumbing and other specifications necessary for a complete understanding of the scope of work for this Project." 1.14. "Drawings" means all drawings and specifications reviewed and accepted by the County which have been prepared by the Architect showing the Work to be done. 1.15. "Guaranteed Maximum Price" and "GMP" mean that maximum amount for which the Work shall be accomplished. 1.16. "Notice to Proceed with Construction Services"means written notice from the Project Manager to the CM with direction to commence the Construction Services, subject to the conditions of this Agreement. 2 1.17. The "Project" means the total design and construction of which the Work performed under the Contract Documents is a part, and may include construction by the County or by separate Contractors. 1.18. "Project Manager" means the individual appointed by the County to act as the County's representative. 1.19. "Subcontractor" means a person, firm, corporation, or other entity supplying labor and materials, or only labor, for the Work, under separate contact or agreement with the CM or any other subcontractor. 1.20. "Supplier" means any manufacturer, fabricator, distributor, material-man or vendor. 1.21. "Value Engineering" means the technical review and analysis of systems and materials being considered in the design to produce the greatest value for the least cost, the object of which is to achieve the optimum value for each construction dollar spent and keep the fiscal constraints set forth throughout the Contract Documents. 1.22. "Work" means the preconstruction services and, if Contractor is selected as the CM, the construction services and all other services required by the Contract Documents, including all other labor, materials, equipment and services provided or to be provided by the CM to fulfill Contractor's obligations. The Work may constitute the whole or a part of the Project. 2. Work: 2.1. Preconstruction Services: Contractor shall perform those preconstruction services that are normally and customarily provided during the planning and design phases of project of this nature, as more fully described in Eagle County's Request for Proposal and Qualifications, Preconstruction Services, for Eagle County Building Roof Replacement, Eagle, Colorado, attached hereto as Exhibit "A," and incorporated herein by this reference (the "Preconstruction Services") and as identified in the CM Fee Structure attached hereto as Exhibit `B" and incorporated herein by this reference. The Preconstruction Services are generally described as the follows: A. Contractor will consult with, advise, assist and make recommendations to the County and Architect on all aspects of planning for the Project, including review and validation of plans, cost estimates and schedules. B. Contractor will designate a competent representative ("Preconstruction Representative"), and any necessary assistance, all satisfactory to the Eagle County Project Manager, to attend at least bi-weekly meetings, commencing immediately and continuing throughout the design phase of the project, as requested with the Architect and/or County to advise and discuss the preconstruction progress and respond to questions regarding the Project. As of the date of execution of this Agreement, Contractor has designated Rodney Turner its Preconstruction Representative. The Preconstruction Representative 3 shall not be changed except with the consent of the Eagle County Project Manager, which consent shall not be unreasonably withheld. C. Contractor will assist the Architect and County at any point in the pre- construction process to provide cost analysis comparisons of various materials, products, or design options. D. Contractor will provide Value Engineering services through technical review and analysis of alternative designs, systems, and materials being considered in the design to produce the greatest value for the least cost. Contractor will provide cost estimates of the alternatives and evaluate the alternatives on the basis of costs, time schedules, availability of labor and materials, construction feasibility, warranties and projected life expectancy. E. Contractor will make budget estimates based on the two existing Design Options and other available information. Contractor will review and refine subsequent estimates with quantity take-off cost estimates in increasing detail as the development of the plans and specifications proceeds, and will advise the County and the Architect if it appears that the targets for the Project budget and/or completion will not be met. F. After the final design is selected, Contractor will provide pricing for the 100% Design Documents. Contractor will then compile Final Pricing, to include hard bid subcontractor pricing, plus any other estimates and projections, for a comprehensive final cost estimate which shall be presented to County as a Guaranteed Maximum Price ("GMP"). Contractor will present the GMP, a detailed budget and construction schedule within 10 working days of the issue of the 100% Construction Documents. The GMP, budget and construction schedule must be approved by the Eagle County Project Manager and the County before the Design and Construction Documents are implemented and the construction services may commence upon the Eagle County Project Manager's issuance of a Notice to Proceed with Construction Services. G. Contractor will review plans and specifications with the Architect for accuracy and completeness and endeavor to eliminate areas of conflict and overlap in the work to be performed by the various subcontractors. H. Contractor will assist the design team in making recommendations of sequencing based on the project parameters for determining the most cost effective construction sequence. Contractor will provide a preliminary critical path schedule for the completion of the design phase, procurement of long lead items and construction phase to achieve substantial completion by November 1, 2013. I.Contractor will maintain an "Open Book" with the County and agrees to provide copies of all data, bids, estimates, takeoffs, and any other supporting documentation generated for pricing, products, materials, and schedule analysis. 4 Some forms, formats and procedures may be construed as proprietary and copyrighted material. Although available for review by County, said materials such as estimating and project management information written, developed and implemented by Contractor shall not become public information. J. Contractor will assist County in obtaining Building Permits if requested. 2.2. Issuance of Notice to Proceed with Construction Services: A. If after completing Preconstruction Services, Contractor's proposed GMP, detailed budget and construction schedule are accepted by County, then County shall provide Contractor with a Notice to Proceed with Construction Services as the Construction Manager ("CM"). Any modifications to this Agreement shall be recorded in writing as an addendum. B. County, in its sole discretion, may decide not to proceed with the Project or with Contractor as the CM, or County may decide not to issue a Notice to Proceed with Construction Services to Contractor for any reason or no reason at all. In the event County does not proceed with the Project or does not select Contractor as the CM prior to commencement of Construction Services, Contractor will be paid for preconstruction services performed to that point, time and materials inclusive, in an amount not to exceed Five Thousand Dollars ($5,000). C. Upon receipt of a Notice to Proceed with Construction Services, Contractor shall carry out and develop the overall plans produced by the Architect that have been pre-. approved by the Eagle County Project Manager; establish procedures for coordination between the Architect and Contractor's subcontractors with respect to all aspects of the Construction Services and implement such procedures; and supervise and direct the work of its subcontractors and coordinate the Work with the County's objectives of cost, time and quality, all in accordance with Section 2.3 herein. 2.3. Construction Services In the event County issues to Contractor a Notice to Proceed with Construction Services, the work and services to be provided shall include,but will not be limited to, the following hereinafter, the"Construction Services"): A. Contractor shall furnish labor and Construction Services (1) which expeditiously, economically and properly complete the Project in the manner most consistent with the County's interests and objectives; and (2) in accordance with the highest standards currently practiced by persons and entities performing comparable labor and services on projects similar in size, complexity and cost in the State of Colorado. B. Supervision: Contractor shall supervise and direct the Construction Services, and shall be solely responsible for all construction means, methods, techniques, sequences, and procedures and shall coordinate all portions of the Work under this Agreement. Contractor shall be responsible to County for the acts and omissions of Contractor's 5 subcontractors, agents, employees and any other persons performing any of the Work or furnishing materials under a contract with Contractor. C.Meeting Attendance: Contractor shall meet regularly with the Architect and Eagle County Project Manager to discuss progress,present material and information and respond to questions regarding the Project. Contractor will be responsible for submitting to the Eagle County Project Manager, within five working days, the minutes of all meetings during the preconstruction and construction phases. Schedule and conduct weekly progress meetings at which subcontractors, Architect, the Eagle County Project Manager, and Contractor can discuss jointly such matters as progress, problems and scheduling. D.Schedule: Within ten (10) working days of issuance of the 100% Design Documents, Contractor shall prepare and submit a construction schedule for the Construction Services which shall provide for the expeditious practicable execution of the Construction Services. The schedule shall be consistent with the previously issued schedules, not exceed time limits current under this Agreement and shall be related to the entire project to the extent required by this Agreement. The schedule for the performance of the work shall be a Critical Path Method or Bar Chart system. Contractor shall provide a detailed schedule for the operation of Contractor and subcontractors on the project, including realistic activity sequences and durations, allocation of labor and materials, processing of shop drawings and samples and delivery of products requiring long lead- time procurement. E.Project Construction Budget: Contractor shall review the project budget and advise the Eagle County Project Manager if it appears that the Project Construction Budget will not be met and make recommendations for corrective action. Contractor shall develop and monitor an effective system of Project cost control; incorporated approved changes as they occur; develop cash flow reports and forecasts as required; identify any variance between actual and budgeted costs within project budgets; advise Architect and Eagle County Project Manager whenever projected costs are expected to vary from the projected budget and/or the Guaranteed Maximum Price, and continually monitor the cost estimates to assure that the Work remains within the applicable budget of the Guaranteed Maximum Price. F.Coordination of Contract Documents: Contractor shall review the drawings and specifications and recommend alternative solutions whenever design details affect construction feasibility of schedules. G. Plan Review: Contractor shall review plans and specifications with the Architect and the Eagle County Project Manager so as to reduce areas of conflict and for coordination, accuracy and completeness of the plans and specifications at the issue of the construction documents. H. Labor: Contractor shall arrange and provide all labor necessary to accomplish and complete the Construction Services and analyze the types,quantity and availability of appropriate categories of labor required for various phases of the Project. 6 I. Project Control: Contractor shall monitor the work of the subcontractors and coordinate the work with the activities and responsibilities of the Eagle County Project Manager and the Architect to complete the Project in accordance with the construction documents and Eagle County's objectives of cost, time and quality. J.Organization: Contractor shall establish on-site organization and lines of authority in order to carry out the overall plans of the Construction Documents. K. Communication: Contractor shall establish procedures for coordination among the Eagle County Project Manager, the Architect, subcontractors and Contractor with respect to all aspects of the Project and implement such procedures. L.Monitoring: Contractor shall provide regular monitoring of the schedule as construction progresses. Identify potential variances with the scheduled completion dates. Review schedule for Work not started or incomplete and recommend to the Eagle County Project Manager and the Architect adjustments in the schedule to meet the Completion Date. Provide summary reports of each monitoring and document all changes in schedule. Determine the adequacy of the subcontractors' personnel and equipment and the availability of materials and supplies to meet the schedule. M. Cost Control: Contractor shall develop and monitor an effective system of project cost control, showing actual costs for activities in progress and estimates for uncompleted tasks. Incorporate approved changes as they occur. N.Permits and Fees: Contractor shall apply for a building permit for the Facility. County will pay the direct cost for the building permit. Contractor shall secure all other permits, including grading, mechanical and electrical permits applicable to subcontractor work and any other special permits for permanent improvements not previously obtained by Eagle County. 0.Staffing: Contractor shall keep on the Project at all times, during its progress, Justin Pronga , as project superintendent ("Superintendent"), and any necessary assistants, including a Project Manager, all satisfactory to the Eagle County Project Manager, to coordinate and provide general direction of the work and progress of the subcontractors on the Project. Contractor's Superintendent or Project Manager shall not be changed except with the consent of Eagle County's Project Manager, such consent to not be unreasonably withheld. Contractor's Superintendent and Project Manager shall represent Contractor and all direction given to it shall be as binding as if given to Contractor. P.Contractor shall provide full-time,qualified and efficient supervision of the Work, using their best skill and attention. Contractor shall carefully study and compare all drawings, specifications and other instructions and shall report to the Eagle County Project Manager, and immediately correct any error, inconsistency or omission which it may discover. Contractor shall inspect the work of the subcontractors at all stages and at final completion and shall guard Eagle County against defects and deficiencies in such work. Contractor shall be responsible to Eagle County for the acts and omissions of all its 7 employees and agents and all other persons performing any of the work under a contract, for which Contractor has supervisory or inspection responsibility hereunder. Q.Safety: Contractor shall be responsible for the safety of persons and property and for compliance with all federal, state and local statutes roles, regulations and orders applicable to the conduct of the Construction Services. R.Shop Drawings and Samples: In collaboration with the Architect, Contractor shall establish and implement procedures for expediting the processing and approval of shop drawings and samples. S.Reports and Project Site Documents: Contractor shall record the daily progress of the Project in a daily log available to the County and the Eagle County Project Manager. Submit on a monthly basis written progress reports and summaries of meetings to the Eagle County Project Manager, including information on the subcontractors' work, the actual cost vs. budgeted cost, actual construction point vs. projected schedule point, reasons for any discrepancies, the percentage of completion and the corrective actions to obtain compliance with time and cost schedules. T.Record Maintenance: Contractor shall maintain at the Project site, on a current basis, records of all necessary contracts, shop drawings, samples, purchases, materials, equipment, maintenance and operating manuals and instructions and any other documents and revisions thereto which arise out of this Agreement or the Construction Services. U.Project Completion: Contractor shall determine Project Completion of designated portions of the Work and prepare for the Eagle County Project Manager a list of incomplete or unsatisfactory items and a schedule for their completion. 3. Time of Performance: 3.1 Contractor shall begin the Preconstruction Services upon full execution of this Agreement by both parties. Contractor shall complete its design and budget review and provide County with its GMP, a detailed budget and final construction schedule on or before August 23, 2013, provided 100% design documents are provided to Contractor in accordance with Article 2.1 F. 3.2. Contractor agrees that Construction Services shall commence upon ten (10) days of County's issuance of a Notice to Proceed with Construction Services and all Construction Services shall be substantially completed in accordance with the construction schedule approved by the Project Manager. In no event shall the Completion Date for Construction Services be later than 60 calendar days from issuance of the Notice to Proceed, absent written agreement for an extension of time in accordance with Section 4 below. 8 4. Liquidated Damages: 4.1. Eagle County and Contractor recognize that time is of the essence of this agreement and that County expects the Project to be substantially complete in accordance with the construction schedule approved by the Project Manager. They also recognize the delays, expense, and difficulties involved in proving a legal or arbitration preceding the actual loss suffered by Eagle County if the Project is not substantially complete in accordance with the approved schedule. Accordingly, instead of requiring such proof, Eagle County and Contractor agree that as liquidated damages (but not as a penalty) for delay beyond the completion date indicated in the schedule approved by County, Contractor shall pay County two hundred dollars ($200.00) for each day that expires after the completion date indicated in the schedule approved by the County, until the Project is complete. 4.2. If Contractor believes that a contract extension should be granted due to delays caused by excusable, inclement weather, it may request a contract extension in writing from the Eagle County Project Manager. Eagle County shall thereon grant an extension equal, in Eagle County's reasonable opinion, in duration to the delay, if any, that was caused by the excusable, inclement weather. Excusable, inclement weather is excessive snowfall, excessive rainfall, excessive freezing temperatures or excessive wind conditions, the degree or duration of which varies in excess of the average conditions expected, which is unusual for the particular time and place where the work is to be performed, or which could not have been reasonably anticipated by Contractor. 4.3. The completion dates as set forth in Paragraphs 4.1 and 4.2 above include a reasonable time for the reviews and approvals required by this agreement. Should Contractor be unreasonably delayed by the failure of any person or entity to provide review or approval within such reasonable time, Contractor shall be entitled to an appropriate extension of time after a written request for such extension has been submitted to and approved by the Eagle County Project Manager in writing. No time extension will be granted unless a determination is made by Eagle County, in its sole discretion that good cause exists for such extension. 4.4. All time extensions shall be made pursuant to Paragraph 7 of the General Conditions. 5. Compensation and Payment: 5.1. County has established a cost not to be exceeded for the entire scope of Work, including Preconstruction Services and Construction Services, including contingencies, based on consultation with the Architect and Contractor, ("Guaranteed Maximum Price" or "GMP"). The funds appropriated for this Project will be equal to or in excess of the Guaranteed Maximum Price. 5.2. County shall pay Contractor an amount not to exceed Five Thousand Dollars ($5,000) for Preconstruction Services described in Paragraph 2.1, subject to Paragraph 5.4 hereunder. 5.3. Additional Services, if requested by the County and approved in writing in advance of performance, that are determined by the County and Contractor not to be similar in nature as described in Paragraph 2.1 through Paragraph 2.3 shall be paid to Contractor based on a GMP approved by County, which includes construction costs (or "Direct Cost of Work") as well as CM Fees that are in line with Contractor's proposal for the Roof Replacement, Eagle, Colorado, dated July 12, 2013, attached hereto as Exhibit"C" and incorporated herein by this reference. 5.4. Notwithstanding the foregoing, neither party represents that the Project will be constructed or that Contractor will be the CM in the event of Construction on this Project. It is agreed that in the event Contractor is selected for Construction Services the Construction Services Fee will be established at 18% of the direct cost, exclusive of the Preconstruction Services Costs and Insurance as per Exhibit C. 5.4.1. Construction Services Fee shall include all overhead and profit. Overhead shall include Contractor's off site costs, including, but not limited to, those for scheduling, estimating and support of the project. This amount is to include the Cost for key personnel and other off site office staff. Profit means before tax profit. On-site costs of construction will be considered a part of the costs of the work and these costs are not to be included in the fee. Costs to be included in the Construction Services Fee shall include only those services and other items identified under the CM Basic Fee column in the CM Fee Structure attached hereto as Exhibit D „ 5.4.2. Adjustments in Construction Services Fee for additions or other changes that are directed by County to increase the scope of Work and related construction costs shall only be made as follows: A. After the initial GMP is accepted by County and County's Project Manager, additions to or other changes that increase the scope of work as approved by the County's Project Manager shall be subject to the Change Order Markup item 3 of Exhibit C. 5.5. Abandonment or significant reduction in the scope or magnitude of the Project will not result in a negotiated reduction of the Construction Services Fee. The Construction Services Fee will be based on the GMP and will not be subject to reduction if the GMP can be reduced through the efforts of Contractor via procurement efforts or other cost saving construction methods. 5.6. The GMP shall include all of the Contractor's obligations to be performed pursuant to the terms of the Contract Documents and include actual fees and costs as outlined below: A. All items identified under "Preconstruction Fee," "CM Basic Fee," and "Direct Cost of Work"in the CM Fee Structure attached hereto as Exhibit"D." B. All items described in Contractor's CM Fee Proposal Form, dated August 8, 2013, attached as Exhibit"C"to this Agreement, C. All Preconstruction Services Fees, Construction Services Fees and Direct Cost of Work charges shall include: 10 a. Actual wages paid for labor in the direct employ of Contractor in the performance of the Work under applicable collective bargaining agreements, or under a salary or wage agreed upon by Eagle County's Project Manager and Contractor and including other benefits, if any, as may be payable with respect thereto. If these wages are under applicable collective bargaining agreements the termination date of such agreements must be included. b. Actual salaries of Contractor's employees wherever stationed and in whatever capacity employed. c. Actual cost of pension contributions, hospitalization, vacations, medical insurance, assessments or taxes for such items as unemployment compensation and social security, insofar as such cost is based on wages, salaries or other remuneration paid to employees of Contractor and included in the cost of the Work. d. The reasonable transportation, traveling and hotel expenses of Contractor or of its officers or employees incurred in discharge of duties connected with the Work. e. Actual cost of all materials, supplies and equipment incorporated in the Work, including costs of transportation thereof. Also includes any material in excess of those actually installed but required to provide reasonable allowance for waste and spoilage. f. Actual payment made by Contractor to subcontractors for work performed pursuant to contract under this Agreement. g. Actual cost, including transportation and maintenance, of all materials, supplies, equipment, temporary facilities and hand tools not owned by the workmen, which are employed or consumed in performance of the Work and costs less salvage value on such items used but not consumed which remain property of Contractor. h. Actual rental charge of all necessary machinery and equipment, exclusive of hand tools, used at the site of the Work, whether rented from Contractor or other, including installation, repairs and replacement, dismantling, removal, costs of lubrication, transportation and delivery costs thereof, at rental charges consistent with those prevailing in the area. i. Cost of the premiums for all bonds and insurance which are required by the Contract Documents. j. Mechanical,Electrical and Plumbing Permit fees, 11 k. Minor expenses such as telegrams, long distance telephone calls, telephone service at the site, expressive and similar petty cash items in connection with the Work. 1. Cost of removal of all debris. m. Cost incurred due to an emergency affecting the safety of person and property, to the extent not compensated by insurance or otherwise. n. Other costs incurred in the performance of the Work if and to the extent approved in advance in writing by the Eagle County Project Manager. o. All costs directly incurred in the performance of the Work and not included in the Construction Services Fee. p. Cost of construction support activities such as Work items included in the condition of the contract and in the specifications unless they are provided by contractors. q. Indirect costs(General Condition Fees). r. Construction Services Fee, as set forth in Exhibit"C." s. One set of as-built drawings. t. Two (2) complete bound sets of required operations and maintenance manuals and instructions. 5.6.1. The GMP includes General Conditions/General Requirements. Contractor will submit for review and acceptance by County an itemized breakdown of the Fees for the Project in accordance with Exhibits C and D of this Agreement. 5.6.2. Any project savings, below the Guaranteed Maximum Price, resulting from bidding of subcontractors and other costs of the work shall accrue to the County. 5.7. The funds appropriated for this Project are equal to or in excess of the contract amount. Notwithstanding anything to the contrary contained in this Agreement, no charges shall be made to County nor shall any payment be made to Contractor in excess of the above amounts for any work done without the written approval of the County in accordance with a budget adopted by the Board of County Commissioners in accordance with the provisions of the Colorado Revised Statutes. 5.8. Payment Procedure for Preconstruction Services. Not more often than once a month, Contractor shall submit to County an invoice for payment signed by a person authorized to sign legal documents on behalf of Contractor identifying the work completed as of the date of the invoice, and accompanied by such supporting documentation as County may reasonably require. 12 For Preconstruction Services, County agrees to pay Contractor within thirty (30) days of receipt of a properly documented invoice. 5.8.1. Payment Procedure for Construction Services If Contractor is selected as the CM; Contractor shall submit applications for payment and back-up material (e.g. Subcontractor's invoices, vender statements and receipts) as shall be reasonably required in accordance with the General Conditions. Applications for payment must be provided on AIA forms G702 and G703 in written or electronic form. These applications shall indicate the percentage of completion of each portion of the Construction Services as of the end of the period covered by the application for payment. Applications for Payment will be processed as provided in the General Conditions. 5.8.2. PROGRESS PAYMENTS: County shall make monthly progress payments on account of the Contract Price on the basis of Contractor's Applications for Construction Agreement Payments, as provided below. All progress payments will be on the basis of the progress of the Work. County shall have the right to request and inspect supporting documentation for progress payments, including but not limited to receipts and invoices evidencing payments of charges associated with the Work. Prior to Completion,progress payments will be in an amount equal to: Ninety-five percent of the calculated value of Work completed and materials and equipment not yet incorporated in the Work but delivered and suitably stored, less in each case the aggregate of payments previously made. The withheld percentage of the Contract Price may be retained until the Work is completed satisfactorily and finally accepted by County as provided for herein. 5.8.3. FINAL PAYMENT: Except as provided by Section 5.9 of this Agreement, within sixty 60) days of completion and acceptance of the Work by County in accordance with Section 17 of this Agreement and Paragraphs 20 and 21 of the General Conditions, County shall pay the remainder of the Contract Price. The final payment shall not be made until after final settlement of this contract has been duly advertised at least ten days prior to such final payment by publication of notice thereof at least twice in a public newspaper of general circulation published in Eagle County, and the Board of County Commissioners has held a public hearing, thereupon and complied with C.R.S. §38-26-107. Final payment shall be made in accordance with the requirements of the aforesaid statute. 5.9 County may withhold from any payments due to Contractor, to such extent as may be necessary to protect the County from loss, because of defective work or material not remedied or the failure of Contractor to carry out the Scope of Work in accordance with this Agreement. 5.10. Contractor shall maintain comprehensive, complete and accurate records and accounts of its performance relating to this Agreement for a period of three (3) years following termination, which period shall be extended at County's reasonable request. County shall have the right within such period to inspect such books, records and documents upon demand, with reasonable notice and at a reasonable time. 13 6. Independent Contractor: It is expressly acknowledged and understood by the parties hereto that nothing contained in this Agreement shall result in, or be construed as establishing, an employment relationship. Contractor shall be, and shall perform as, an independent contractor. No technician, agent, subcontractor, employee, or servant of Contractor shall be, or shall be deemed to be, the employee, agent or servant of County. Contractor shall be solely and entirely responsible for its acts and for the acts of its technicians, agents, employees, and servants during the performance of this agreement. Contractor shall not represent, act, purport to act or be deemed the agent, representative, employee or servant of County. 7. No Assignment: The parties to this Agreement recognize that in entering into this Agreement, County is relying upon the resources, skill and reputation of Contractor. Therefore, Contractor may not assign its interest in the Agreement, including the assignment of any rights or delegation of any obligations provided therein, without the prior written consent of County, which consent County may withhold at its sole discretion. Except as so provided, this Agreement shall be binding on and inure to the benefit of the parties hereto, and their respective successors and assigns, and shall not be deemed to be for the benefit of or enforceable by any third party. Unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Agreement. 8. Subcontracts: 8.1. All portions of the Work that Contractor does not perform with its own forces shall be performed under subcontracts by subcontractors prequalified by Contractor. 8.2. All subcontracts will be between Contractor and the subcontractors. 8.3. Contractor shall be responsible to the County for the acts and omissions of its agents, employees, suppliers, subcontractors performing work under a contract with Contractor and such subcontractors' lower-tier subcontractors, agents and employees. 8.4. By an appropriate written agreement, Contractor shall require the subcontractor to the extent of the Work to be performed by the subcontractor, to be bound to Contractor by the terms of the Contract Documents and to assume toward Contractor all the obligation and responsibility which Contractor, by these Documents, assumes toward the County. Said agreement shall preserve and protect the rights of the County under the Contract Documents with respect to the Work to be performed by the subcontractor so that the subcontracting thereof will not prejudice such rights. Contractor shall require each subcontractor to enter into similar agreements with its subcontractors. Contractor shall make available to each proposed subcontractor, prior to the execution of the subcontract, complies of the Contract Documents to which the subcontractor will be bound by this paragraph 8.6. Each subcontractor shall similarly make copies of such Documents to its subcontractors. 8.5. Each Subcontract and material purchase order is hereby assigned to County by Contractor provided that (a) assignment is effective only after termination of the Contract by County for cause and only for those subcontract agreements which County accepts by notifying the subcontractor and Contractor in writing; and (b) assignment is subject to the prior rights of the surety, if any, obligated under the bond relating to the Project. Each subcontract and material purchase order shall include this assignment. 8.6. Nothing contained in the Contract Documents shall be deemed to create any contractual relationship between any subcontractor of any tier and the County. 9. Insurance: At all times during the term of this Agreement, Contractor and its subcontractors shall maintain the following insurance: 9.1. Claims under Workmen's Compensations, disability benefits, and other similar employee benefit acts,with coverage and in amounts as required by the laws of the State of Colorado. 9.2. General Liability Coverage in the minimum amount of$2,000,000 (Combined personal injury/property damage limit) for coverage of claims for damage arising from the performance of services under this Agreement, including but not limited to personal injury or death, property damage, and other damages imposed by law upon Contractor with respect to all work performed by them. 9.3. Comprehensive Automobile Insurance in the amounts as required by the laws of the State of Colorado. 9.4. Certificates of Insurance acceptable to the County, evidencing the above required amounts shall be filed with the County within ten (10) days from the execution of this Agreement. 10. Indemnification: Contractor shall indemnify County for, and hold and defend County and its officials, boards, officers, principals and employees, harmless from, all costs, claims and expenses, including reasonable attorney's fees, arising from claims of any nature whatsoever made by any person in connection with the performance of this Agreement to the extent such cost, claim and expense is caused in whole or in part by the negligent or willful acts or omissions of Contractor. 11. Contractor Representations: 11.1. Contractor expressly recognizes that this Project must be completed within the time and fiscal constraints set forth throughout this Agreement. 11.2. Contractor further represents to the County that, by executing this Agreement, it has been informed of and has reviewed the goals of the Project; the design of the Architect; the time schedule as well as fiscal constraints of the Project; all of the Exhibits and documents attached to 15 this Agreement, and incorporated herein by reference; and, all of the services to be provided by Contractor pursuant to the Contract Documents. Based upon this review and analysis, Contractor represents to County that it will provide all of the necessary services and perform all of the Work within the requirements of the Contract Documents. 11.3. Contractor shall perform the Scope of Work in a skillful, professional and competent manner and in accordance with the standards of care, skill, and diligence applicable to other contractors performing this type of work. 11.4. Contractor shall be responsible for the completeness and accuracy of the Work and shall correct, at its sole expense, all errors and omissions therein. The fact that County has accepted or approved the Work shall not relieve Contractor of any if its responsibilities under this Agreement. 11.5 Contractor acknowledges it is Contractor's responsibility to review all design and construction documents relating to constructability and potential conflicts. The purpose of this review is to minimize change orders due to conflicts in the Construction Documents to the greatest extent possible. 12. Contract Documents The Contract Documents which comprise the entire Agreement are made a part hereof and consist of the following: 12.1. This Agreement. 12.2. Exhibit"A": General Conditions. 12.3. Exhibit"B": Eagle County Government Building Re-Roof, Roof Plan dated 6/20/13 by Menendez Architects P.C. 12.4. Exhibit"C": Construction Management Fee Proposal Form, Eagle County Building Roof Replacement, Eagle Colorado,dated July 24, 2013 12.5. Exhibit"D": Construction Management Fee Structure, Eagle County Building Roof Replacement, Eagle Colorado, dated July 22, 2013. There are currently no Contract Documents other than those listed above in this Article 12. If County accepts Contractor's proposed GMP, budget and schedule and thereby selects Contractor as the CM/GC,the budget, schedule,and final plans and specifications (as submitted to the Town of Eagle for a building permit) will become part of the Contract Documents. Thereafter, the Contract Documents may only be altered, amended, or repealed by an executed, written change order or other amendment to this Agreement. The intent of the Contract Documents is to include all items, components and services necessary for the proper execution and completion of all the Work outlined in Section 2 of this Agreement. The Contract Documents are complementary, and what is required by any one shall be as binding 16 14.2. If either party defaults or Contractor neglects to carry out the Work in accordance with this Agreement and fails within a ten (10) day period after receipt of written notice from the other party to correct such default or neglect with diligence and promptness, the other party may, without prejudice to other remedies, terminate this agreement. If Contractor fails to correct such deficiencies after timely notification by County, County may in addition to or as an alternative to termination correct such deficiencies and deduct the cost of correction from payments due Contractor. County may recover the reasonable costs of correcting deficiencies in an amount not exceeding that specified in the Agreement. 14.3. Upon the termination of this Agreement, Contractor agrees to deliver to County such information and items which, if this Agreement had been completed, would have been required to be furnished to the County, including completed or partially completed plans, drawings, red- lined drawings and other pertinent information, in an electronic form or otherwise, in a format usable by the County. 15. Drawings and Specifications 15.1. OWNERSHIP AND USE OF DOCUMENTS —All drawings, specifications, and copies thereof furnished by the County are and shall remain the property of the County. They are to be used only with respect to this Project and are not to be used on any other project. With the exception of one contract set for each party to this Agreement, such documents are to be returned or suitably accounted for to the County on request at the completion of the Work. Submission or distribution to meet official regulatory requirements or for other purposes in connection with the Project is not to be construed as publication in derogation of the County's common law copyright or other reserved rights. 15.2. INTERPRETATIONS - The Architect may be asked to render interpretations consistent with the intent of, and reasonably inferable from the Contract Documents, consisting of additional instructions by means of drawings or otherwise necessary for the proper execution or progress of the Work, in accordance with agreed upon time limits and otherwise so as to cause no unreasonable delay. Contractor may make written request to the Architect of such interpretations and decisions. Contractor shall comply with the Architect's interpretations and such interpretation shall be incorporated into this Agreement, subject to County's review and final determination in those instances deemed necessary by the County. 16. Completion of the Work 16.1.1. When Contractor considers that the Work or a designated portion thereof is complete as defined in paragraph 2.3, Contractor shall notify County of the Completion of the Work and prepare a list of items to be completed or corrected. 16.1.2. Within ten (10) days after receipt of Contractor's notice of completion of the Work, the County,Architect and Contractor shall make an inspection of the Work to determine whether the Work has been completed in accordance with the Contract Documents and to prepare a punch list. If the Work has not been completed to the required stage, the parties shall cease the inspection and an appropriate Change Order shall be issued deducting from the payments then or thereafter due Contractor all costs associated with such premature inspection, including 18 compensation for the Architect's additional services, if made necessary thereby. If the payments then or thereafter due Contractor are not sufficient to cover such amount, Contractor shall pay the difference to the County. If however, the Work has been completed to the required stage, a punch list shall be prepared by Architect and/or County and consist of those items listed by Contractor to be completed or corrected as supplemented by those items observed and noted during the inspection. The required number of copies of the punch list will be countersigned by the County Project Manager or other authorized County representative and the Architect and will then be transmitted to Contractor. The failure to include any items on such list shall not alter the responsibility of Contractor to complete all Work in accordance with the Contract Documents. 16.2. RIGHT OF EARLY OCCUPANCY 16.2.1. The County shall have the right to take possession of and to use any completed or partially completed portions of the Work, even if the time for Completion of the Work or such portions of the Work has not expired and even if the Work has not been finally accepted. Such possession and use shall not constitute an acceptance of such portions of the Work. 16.2.2. If the County elects to take possession of and to use any completed or partially completed portions of the Work prior to the time for Completion of the Work or portion thereof, prior to any such possession or use, an inspection shall be made by the local jurisdiction, the Project Manager and Contractor. Any and all areas so occupied will be subject to a final inspection when the Contractor complies with Article 16.1. 16.2.3. At the time of the inspection made pursuant to paragraph 16.2.2., the parties shall also agree upon the responsibilities of the County and Contractor for security, maintenance, heat, utilities, property insurance premiums, and damage to the Work. If Contractor can also satisfactorily demonstrate to the County any actual cost for warranties for the period prior to the date of Notice of Acceptance,the County shall reimburse Contractor for that portion of such cost attributable to the portion of the Work occupied by the County for the period of time of such occupancy. In the event Contractor believes there will be an additional cost associated with completion of the Work while the County occupies the Work in whole or in part, Contractor shall advise the County of all such cost at or before the time of the inspection and an agreement shall be reached on the responsibilities of the County and Contractor therefor. If Contractor fails or refuses to furnish such cost information as required, Contractor hereby waives any and all rights to assert any claim therefor at any time thereafter. 17. Final Completion,Acceptance,and Final Payment 17.1. Following County's issuance of the Certificate of Completion of the Work or designated portion thereof, the issuance or a Certificate of Occupancy from the local jurisdiction if required, and Contractor's completion of the work on the punch list established pursuant to paragraph 16.1.2. as may have been supplemented, Contractor shall forward to the County a written notice that the Work is ready for final inspection and acceptance, and shall also forward to the County a final application for Payment. Upon receipt, the County and Architect will promptly make such inspection. When the Architect finds the Work acceptable under the Contract Documents, Architect will issue a Final Certificate of Completion. This Certificate will constitute a representation that, to the best of the Architect's knowledge, information and belief, and on the 19 basis of observations and inspections, the Work has been completed in accordance with the terms and conditions of the Contract Documents. 17.2. NOTICE OF ACCEPTANCE — When the local jurisdiction has issued a Certificate of Occupancy, Architect has issued its Final Certificate of Completion, Contractor has fully performed all of its obligations under the Contract Documents and the same is acceptable to the County, a Notice of Acceptance shall be issued by the County, which shall establish the acceptance of the Work. 17.3. SETTLEMENT 17.3.1. The County shall not authorize final payment until all items on the punch list have been completed, the Architect issues its Final Certificate of Completion, County has received a Certificate of Occupancy from the local jurisdiction, the Notice of Acceptance is issued, and the Notice of Contractor's Final Settlement Date is published and at least 30 days have expired with no claims filed. 17.3.2. Before the County may advertise, Contractor shall: 1. Deliver to the Architect for review by the Architect and deliver to the County: a. All guaranties and warranties; b. Confirmation that sales taxes from which the County is exempt have not been paid; c. Two(2)complete bound sets of required operations and maintenance manuals and instructions; d. Two (1) sets of as-built drawings; e. To the extent not already furnished, one copy of all corrected Shop Drawings; f.Satisfactory evidence that all payroll, material bills, and other indebtedness connected with the Work have been paid or otherwise satisfied; g. A complete and final waiver and/or release of any and all lien rights and liens from each subcontractor of all tiers,materialmen, supplier,manufacturer and dealer for all labor, equipment and material used or furnished by each on the Work; h. Consent of the surety to final payment; i.Any other documents required to be furnished by the Contract Documents. 20 2. Demonstrate to the operating personnel of the County the proper operation.and maintenance of all equipment installed or furnished under the Contract Documents. 17.3.3. Upon completion of the foregoing, the Contractor's Settlement shall be advertised in accordance with Colorado law. On the date of final settlement thus advertised, and after the CM has submitted a written notice to the County that no claims have been filed, final payment and settlement shall be made in full. 17.3.4. If any unpaid claim for labor, materials,rental machinery, tools, supplies, or equipment is filed before payment in full of all sums due Contractor, the County shall withhold from Contractor sufficient funds to insure the payment of such claim, until the same shall have been paid or withdrawn, such payment or withdrawal to be evidence by filing a receipt in full or an order for withdrawal signed by the claimant or its duly authorized agent or assignee. 17.3.5. The making of final payment, after the Date of the Notice of Contract Settlement of the Project, shall constitute a waiver of all Claims by the County except those arising from: 1. Unsettled Claims; 2. Faulty or defective work appearing after Completion of the Work; 3. Failure of the Work to comply with the requirements of the Contract Documents; 4. Terms of any warranties or special warranties required by the Contract Documents. 17.3.6. The acceptance of final payment, after the Date of the Notice of Contractor Settlement of the Project, shall constitute a waiver of all Claims by Contractor except those previously made in writing and separately identified by Contractor as unsettled in the final Project Application for Payment. 17.3.7. All provisions of the Contract Documents including without limitation those establishing obligations and procedures, shall remain in full force and effect notwithstanding the making or acceptance of final payments. 18. Warranties 18.1.1. Contractor warrants to the County that all work, materials and equipment furnished under the Contract Documents will be of good quality, free from faults and defects and in conformance with the Contract Documents. All work, materials or equipment not conforming to these requirements, including substitutions not properly approved and authorized, may be considered defective. If required by County, Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment. This warranty is not limited by the provisions of paragraph 18.1.2. 21 expenses incurred by it in correcting such deficiencies and defects, as well as all damages directly resulting form such deficiencies and defects. 19. Claims for Additional Costs and Damages 19.1. CLAIMS FOR ADDITIONAL COST 19.1.1. If Contractor makes a claim for an increase in the GMP, Contractor shall give the County its written notice of Claim thereof within fifteen (15) days or such other time period as may be specifically set forth elsewhere in this Agreement,whichever is the lesser, after the occurrence of the event giving rise to such claim and in all cases before proceeding to execute the Work, except in an emergency endangering life or property, in which case, Contractor shall proceed as necessary to prevent such threat. No such claim shall be valid unless so made. Any approved change in the GMP resulting from such claim shall be authorized by Change Order. 19.2. INJURY TO PERSON OR DAMAGE TO PROPERTY — Should either party to this Agreement suffer injury or damage to person or property because of any act or omission of the other party or of any of the other party's employees, agents, or others for whose acts such party is legally liable, Notice of Claim shall be made in writing to such other party within sixty (60) days after the first observance of such injury or damage. 19.3. RIGHTS AND REMEDIES 19.3.1. The duties and obligations imposed by the Contract Documents and the rights and remedies available thereunder shall be in addition to, and not a limitation of, any duties, obligations, rights or remedies otherwise imposed or available by law. 19.3.2.No action or failure to act by the County shall constitute a waiver of any right or duty afforded under the Contract Documents nor shall any such action or failure to act constitute an approval or acquiescence in any breach thereunder, except as may be specifically agreed in writing. Nothing herein shall waive or be deemed a waiver of the County's governmental privileges and immunities under federal or state law. 20. Miscellaneous: 20.1. The project is under the authority of the Eagle County Facilities Project Management Department, the Director of which, or his/her designee, shall be Eagle County's liaison with Contractor with respect to the performance of the Work. 20.2. Contractor shall not discriminate against any employee or applicant for employment to be employed in the performance of this Agreement on the basis of race, color, religion, national origin, sex, sexual orientation, ancestry, physical handicap, age, political affiliation or family responsibility. 20.3. The making, execution and delivery of this Agreement by the parties hereto have not been induced by any prior or contemporaneous representation, statement, warranty or agreement 23 as to any matter other than those herein expressed. This Agreement embodies the entire understanding and agreement of the parties, and there are no further or other agreements or understandings, written or oral, in effect between them relating to the subject matter hereof. This Agreement may not be amended, including by any modification of, deletion from or addition to the Work, except by a written document of equal formality executed by both parties hereto. 20.4. This Agreement shall be governed by and construed in accordance with the internal laws of the State of Colorado, without reference to choice of law rules. The parties agree that venue in any action to enforce or interpret this Agreement shall be in the District Court in the 5th District for the State of Colorado. 20.5. This Agreement does not and shall not be deemed to confer upon or grant to any third party any right enforceable at law or equity arising out of any term, covenant, or condition herein or the breach thereof. 20.6. The invalidity or unenforceability of any particular provision of this Agreement shall not affect the other provisions hereof, and this Agreement shall be construed as if such invalid or unenforceable provision was omitted. 20.7. In the event of litigation between the parties hereto regarding the interpretation of this Agreement, of the obligations, duties or rights of the parties hereunder, or if suit otherwise is brought to recover damages for breach of this Agreement, or an action be brought for injunction or specific performance, then and in such event,the prevailing party shall recover all reasonable costs incurred with regard to such litigation, including reasonable attorney's fees. 20.8. Time is of the essence and the parties agree to notify the other if they become aware that any condition will significantly delay performance. 20.9. Neither party will be responsible for delays or lack of performance resulting from events beyond the reasonable control of that party. Such events include, but are not limited to, acts of God, weather conditions, fire, third party strikes, third party lock-outs, and other labor disruptions, material shortages, riots,and acts of war. 20.10. All tracings, plans, specifications, estimates, reports, date and miscellaneous items, including electronic data, purported to contribute to the completeness of the Project, the Project or the Work shall be delivered to and become the property of the County,upon County's request. However, all estimating and project management information written, developed and implemented by Contractor shall be available for review by County, but shall not become public information or available for use by any entity other than Contractor. 20.11. Basic survey notes, sketches, computations and other data prepared hereunder shall be made available to the County, upon request and become property of the County. 20.12. The Architect, County,Project Manager and all other representatives of the County shall at all times have access to the Facility to view the progress of the Work,wherever it is in preparation and progress. The Contractor shall provide any necessary safety equipment, and safe and reasonable facilities for such access so that the Architect,Project Manager and County 24 representatives may exercise their rights and perform their functions under the Contract Documents. 21. Prohibitions on Public Contracts for Services: 21.1 If Contractor/Consultant has any employees or subcontractors, Contractor/Consultant shall comply with C.R.S. § 8-17.5-101, et seq., regarding Illegal Aliens — Public Contracts for Services, and this Contract. By execution of this Contract, Contractor/Consultant certifies that it does not knowingly employ or contract with an illegal alien who will perform under this Contract and that Contractor/Consultant will participate in the E-verify Program or other Department of Labor and Employment program ("Department Program") in order to confirm the eligibility of all employees who are newly hired for employment to perform work under this Contract. 21.1.1. Contractor/Consultant shall not: i) Knowingly employ or contract with an illegal alien to perform work under this contract for services; or ii) Enter into a contract with a subcontractor that fails to certify to the Contractor/Consultant that the subcontractor shall not knowingly employ or contract with an illegal alien to perform work under the public contract for services. 21.1.2. Contractor/Consultant has confirmed the employment eligibility of all employees who are newly hired for employment to perform work under this Contract through participation in the E- verify Program or Department Program, as administered by the United States Department of Homeland Security. Information on applying for the E-verify program can be found at: http://www.dhs.gov/xprevprot/programs/gc 1185221678150.shtm 21.1.3. The Contractor/Consultant shall not use either the E-verify program or other Department Program procedures to undertake pre-employment screening of job applicants while the public contract for services is being performed. 21.1.4. 1f the Contractor/Consultant obtains actual knowledge that a subcontractor performing work under the public contract for services knowingly employs or contracts with an illegal alien, the Contractor/Consultant shall be required to: i) Notify the subcontractor and the County within three days that the Contractor/Consultant has actual knowledge that the subcontractor is employing or contracting with an illegal alien; and ii) Terminate the subcontract with the subcontractor if within three days of receiving the notice required pursuant to subparagraph (i) of the paragraph D) the subcontractor does not stop employing or contracting with the illegal alien; except that the Contractor/Consultant shall not terminate the 25 contract with the subcontractor if during such three days the subcontractor provides information to establish that the subcontractor has not knowingly employed or contracted with an illegal alien. 21.1.5. The Contractor/Consultant shall comply with any reasonable request by the Department of Labor and Employment made in the course of an investigation that the department is undertaking pursuant to its authority established in C.R.S. § 8-17.5-102(5). 21.1.6. If a Contractor/Consultant violates these prohibitions, the County may terminate the contract for a breach of the contract. If the contract is so terminated specifically for a breach of this provision of this Contract, the Contractor/Consultant shall be liable for actual and consequential damages to the County as required by law. 21.1.7. The County will notify the office of the Colorado Secretary of State if Contractor/Consultant violates this provision of this Contract and the County terminates the Contract for such breach. Signature Page to Follow// 26 IN WITNESS WHEREOF,the parties hereto have executed this Agreement the day and year first above written. COUNTY OF EAGLE, STATE OF COLORADO, By and Through Its ATTEST: P.11 : p . r f, N I By: ri Clerk the Board of n( T11 i i, Co ty Commissioners CONTRACTOR: COLWEST ROOFING AND WATERPRO• -I _0 MPANY By: --- Signature t w in e.,.-^ Title STATE OF COLORADO SS. COUNTY OF 2c1. l 1 The foregoing instrument was acknowledged before me by TZodneLj N ten Twrner this ,X)m day of R p;uSt 2013. My commission expires: 1Jovernbe.r ISM 201(p c' Notary Public CARA STANGELAND NOTARY PUBLIC STATE OF COLORADO NOTARY ID 20124070004 MY COMMISSION EXPIRES NOVEMBER 15,2016 27 GENERAL CONDITIONS 1. Contractor shall provide and pay for labor, materials, equipment, tools, licenses, transportation, and other facilities and services necessary for proper execution and completion of the Work. 2. If Contractor fails to obtain the tax exemption(s) applicable to public works projects from sales, consumer, use and similar taxes, Contractor shall pay the same. County will cooperate with Contractor to obtain tax exemption for this project. 3. Contractor shall be responsible for having taken steps reasonably necessary to ascertain the nature and location of the Work, and the general and local conditions which can affect the Work or the cost thereof. Any failure by Contractor to do so will not relieve it from responsibility for successfully performing the Work without additional expense to the County. County assumes no responsibility for any understanding or representations concerning conditions made by any of its officers, employees or agents prior to the execution of this Agreement, unless such understanding or representations are expressly stated in the Agreement. 4. Before commencing activities, Contractor shall: (1) take field measurements and verify field conditions; (2) carefully compare this and other information known to Contractor with the Agreement; and(3)promptly report errors, inconsistencies or omissions discovered to County. 5. Contractor shall supervise and direct the Work, using Contractor's best skill and attention. Contractor shall be solely responsible for and have control over construction means, methods, techniques, sequences and procedures, and for coordinating all portions of the Work. 6. Contractor, as soon as practicable, shall furnish in writing to the County the names of subcontractors and suppliers for each portion of the Work. 7. No charge shall be made by Contractor for hindrances or delays from any cause whatever during the progress of any portion of the Work, unless such hindrance or delay is caused in whole or in part by acts or omissions within the control of County or outside the control of Contractor, e.g., weather. In any event, County may grant an extension of time for the completion of the Work, provided it is satisfied that delays or hindrances were due to causes outside Contractor's control, e.g., weather, or to acts of omission or commission by the County, provided that such extensions of time shall in no instance exceed the time actually lost to Contractor by reason of such causes, and provided further that Contractor shall have given County immediate (as reasonably determined by the circumstances, but not exceeding seven (7) calendar days)notice in writing of the cause of the detention or delay. 8. Contractor shall deliver, handle, store and install materials in accordance with manufacturers' instructions. 9. Contractor warrants to County that: (1) materials and equipment furnished under the Agreement will be new and of good quality; (2) the Work will be free from defects not inherent 28 in the quality required or permitted; and (3) the Work will conform to the requirements of the Agreement. 10. Contractor shall comply with and give notices required by all federal, state and local laws, statutes, ordinances, building codes, rules and regulations applicable to the Work. If Contractor performs Work knowing it to be contrary to laws, statutes, ordinances, building codes, rules or regulations without notice to County, Contractor shall assume full responsibility for such Work and shall bear the attributable costs. Contractor shall promptly notify County in writing of any conflicts that Contractor discovers between the specifications for the Work and such governmental laws, rules and regulations. 11. Contractor shall keep the premises and surrounding area free from accumulation of debris and trash related to the Work. 12. Contractor shall furnish performance bond and a separate labor and material payment bond on forms acceptable to the County, each in an amount at least equal to the contract price as security for the faithful performance and payment of all Contractor's obligations under the contract documents. In the event of any change order resulting in the performance of additional work in connection with the Project, the amounts of such bonds shall be increased by an amount equal to the cost of such additional work or materials or fixtures to be incorporated in the Project. Copies of the bonds shall be provided to the County and shall be made payable to the County. These bonds shall remain in effect at least until one year after the date of final payment, except as otherwise provided by law. All bonds shall be executed by such sureties as (a) are licensed to conduct business in the state where the project is located, and (b) are named in the current list of Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies" as published in Circular 570 (amended) by the Audit Staff Bureau of Accounts, U.S. Treasury Department. All bonds signed by an agent must be accompanied by a certified copy of the authority to act. If the surety on any bond furnished by Contractor is declared bankrupt, or becomes insolvent, or its right to do business is terminated in any state where any part of the project is located, or it ceases to meet the requirements of clauses a) and (b) of the preceding paragraph, Contractor shall within five days thereafter substitute another bond and surety, both of which shall be acceptable to County. 13. Contractor shall be solely responsible for the protection of the Work and material. Contractor shall have no claim against County because of any damage or loss to the Work except that caused by negligence of County or those for whom County is responsible), and shall be responsible for the complete restoration of damaged Work to its original condition. In the event Contractor's Work is damaged by another party, not under its supervision or control, Contractor shall make its claim directly with the party involved. If a conflict or disagreement develops between Contractor and another party concerning the responsibility for damage or loss to Contractor's Work, such conflict shall not be cause for delay in Contractor's restoration of the damaged Work. 14. Contractor's Insurance: A. Contractor shall purchase and maintain such insurance as will protect it from claims set forth below which may arise out of or result from Contractor's operations 29 under the contract, whether such operations be by itself, or by any of its subcontractors, or by anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them may be liable. All such insurance shall remain in effect until final payment, and at all times thereafter when Contractor may be correcting, removing, or replacing defective Work. In addition, Contractor shall maintain such completed operations insurance for at least one year after final payment. B. Insurance coverages shall be as follows: Claims under Workmen's Compensation, disability benefits, and other similar employee benefit acts, with coverage and in amounts as required by the laws of the State of Colorado; Claims for damage because of bodily injury, occupational sickness or disease, or death of its employees, and claims insured by usual personal injury liability coverage; Claims for damage because of bodily injury, sickness or disease, or death of any person other than its employees, and claims insured by usual personal injury liability coverage; and Claims for damages because of injury to or destruction of tangible property, including loss of use resulting therefrom. Contractor's Liability Insurance issued to and covering the liability for damage imposed by law upon Contractor and each subcontractor with respect to all Work performed by them under this Agreement. Contractor's Protective Liability Insurance issued to and covering the liability for damages imposed by law upon Contractor and each subcontractor with respect to all Work under this Agreement performed for Contractor by subcontractors. Completed Operations Liability Insurance issued to and covering the liability for damage imposed by law upon Contractor and each subcontractor arising between the date of final cessation of the Work, and the date of final acceptance thereof out of that part of the Work performed by each. Comprehensive Automobile Insurance shall be carried in the amount of 500,000/$1,000,000 for bodily injury and $500,000 for property damage, each occurrence. All liability and property damage insurance required hereunder shall be Comprehensive General and Automobile Bodily Injury and Property Damage form of policy. Comprehensive Risk Policy Option: In lieu of the several policies specified for Contractor's Liability Insurance, a comprehensive liability and property damage insurance policy inclusive of all the insurance and requirements herein set forth, subject to the approval of the County,will be permissible. 30 17. To the fullest extent permitted by law, Contractor shall indemnify and hold harmless County, and Eagle County Board of Commissioners, employees and the agents of any of them, from and against claims, damages, losses and expenses, including but not limited to attorneys' fees, arising out of or resulting from performance of the Work, provided that such claim, damage, loss or expense is attributable to bodily injury, sickness, disease or death, or to injury to or destruction of tangible property (other than the Work itself) including loss of use resulting therefrom, but only to the extent caused in whole or in part by negligent acts or omissions of Contractor, a subcontractor, anyone directly or indirectly employed by them or anyone for whose acts they may be liable. 18. Progress Payments: Not more often than once a month, Contractor shall submit to County an application for payment filled out and signed by Contractor covering the work completed as of the date of the application, and accompanied by such supporting documentation as County may reasonably require. If payment is requested on the basis of materials and equipment not incorporated in the work, but delivered and suitably stored at the site or at another location agreed to in writing, the application for payment shall also be accompanied by such data, satisfactory to County, as will establish County's title to the material and equipment, and protect County's interest therein, including applicable insurance. Each subsequent application for payment shall include an affidavit of Contractor stating that all previous progress payments received on account of the work have been applied to discharge in full all of Contractor's obligations reflected in prior applications for payment. The amount of retention with respect to progress payments will be as stipulated in the Agreement. County will, within ten days after receipt of each application for payment, either indicate in writing a recommendation of payment, or return the application to Contractor indicating in writing its reasons for refusing to recommend payment. In the latter case, Contractor may make the necessary corrections and resubmit the application. County shall, within ten days of recommendation of payment, pay Contractor the amount recommended. 19. Contractor warrants and guarantees that title to all work, materials, and equipment covered by any application for payment, whether incorporated in the project or not, will pass to County at the time of payment free and clear of all liens, claims, security interests, and encumbrances(in these General Conditions referred to as "Liens"). 20. Final Payment: A. Upon written notice from Contractor that the work is complete, County will make a final inspection with Contractor, and will notify Contractor in writing of all particulars in which this inspection reveals that the work is incomplete or defective. Contractor shall immediately take such measures as are necessary to remedy such deficiencies. B. After Contractor has completed all such corrections to the satisfaction of County, and delivered all maintenance and operating instructions, guarantees, bonds, certificates 32 of inspection, Contractor may make application for final payment following the procedure for progress payments. The final application for payment shall be accompanied by all documentation called for in the contract documents, and such other data and schedules as County may reasonably require, together with complete and legally effective releases or waivers (satisfactory to County) of all liens arising out of, or filed in connection with the work. In lieu thereof, and as approved by County, Contractor may furnish receipts or releases in full; an affidavit of Contractor that the releases and receipts include all labor, services, material, and equipment for which lien could be filed, and that all payrolls, material, and equipment bills, and other indebtedness connected with the work, for which County or its property might in any way be responsible, have been paid or otherwise satisfied; and consent of the surety, if any, to final payment. If any subcontractor, manufacturer, fabricator, supplier, or distributor fails to furnish a release or receipt in full, Contractor may furnish a bond or other collateral satisfactory to County to indemnify County against any lien. 21. Final payment shall not become due until Contractor submits to County releases and waivers of liens, and data establishing payment or satisfaction of obligations, such as receipts, claims, security interests or encumbrances arising out of the Work. Final payment is subject to the Final Settlement requirements and time periods set forth in C.R.S. §38-26-107. 21.1 The County shall not authorize final payment until all items on the punch list have been completed,the Architect issues its Final Certificate of Completion,the County has received a Certificate of Occupancy from the local jurisdiction,the Notice of Acceptance is issued, and the Notice of Contractor's Final Settlement Date is published and at least 30 days have expired with no claims filed. 21.2. Before the County may advertise, Contractor shall: A. Deliver to the Eagle County Project Manager for review: 1. All guaranties and warranties; 2. A letter confirming that sales taxes from which the County is exempt have not been paid; 3. Three (3) complete bound sets of required operations and maintenance manuals and instructions; 4. Two(2) sets of as-built drawings; 5. To the extent not already furnished, one copy of all corrected Shop Drawings; 6. Satisfactory evidence that all payrolls, material bills,and other indebtedness connected with the Work have been paid or otherwise satisfied or will be paid evidenced by the provision of conditional lien release waivers; 33 mosimw 7. A complete and final waiver and/or release of any and all lien rights and liens from each subcontractor of all tiers, material,men, supplier, manufacturer and dealer for all labor, equipment and material used or furnished by each on the Work which may be in the form of a conditional lien release waiver conditioned upon final payment by County; 8. Consent of the surety to final payment; and 9. Any other documents required to be furnished by the Contract Documents. B. Demonstrate to the operating personnel of the County the proper operation and maintenance of all equipment. 21.3. Upon completion of the foregoing, Contractor's Settlement shall be advertised in accordance with Colorado law. On the date of final settlement thus advertised,and after Contractor has submitted a written notice that no claims have been filed, final payment and settlement shall be made in full. 21.4. Pursuant to C.R.S. §38-26-107, if any unpaid claim for labor,materials, rental machinery, tools, supplies, or equipment is filed before payment in full of all sums due Contractor, County shall withhold from Contractor sufficient funds to insure the payment of such claim, until the same shall have been paid or withdrawn, such payment or withdrawal to be evidenced by filing a receipt in full or an order for withdrawal signed by the claimant or its duly authorized agent or assignee. 21.5. The making of final payment, after the Date of the Notice of Contractor Settlement of the Project, shall constitute a waiver of all claims by the County except those arising from: A. Unsettled Claims; B. Faulty or defective work appearing after Completion of the Work; C. Failure of the Work to comply with the requirements of the Contract Documents; or D. Terms of any warranties or special warranties required by the Contract Documents. 21.6. The acceptance of final payment, after the Date of the Notice of Contractor Settlement of the Project, shall constitute a waiver of all claims by Contractor except those previously made in writing and separately identified by Contractor as unsettled in the final Project Application for Payment. 34 After receipt of a Notice of Termination, and except as otherwise directed by County,Contractor shall, in good faith, and to the best of its ability, do all things necessary, in the light of such notice and of such requests in implementation thereof as County may make, to assure the efficient, proper closeout of the terminated Work(including the protection of County's property). Among other things, Contractor shall, except as otherwise directed or approved by County: A. stop the Work on the date and to the extent specified in the Notice of Termination; B. place no further orders or subcontracts for services, equipment or materials except as may be necessary for completion of such portion of the Work as is not terminated; C. terminate all orders and subcontracts to the extent that they relate to the performance of Work terminated by the Notice of Termination; D. assign to County, in the manner and to the extent directed by it,all of the right, title and interest of Contractor under the orders or subcontracts so terminated, in which case County shall have the right to settle or pay any or all claims arising out of the termination of such orders and subcontracts; E. with the approval of County, settle all outstanding liabilities and all claims arising out of such termination or orders and subcontracts; and F. deliver to County, when and as directed by County, all documents and all property which, if the Work had been completed, Contractor would be required to account for or deliver to County, and transfer title to such property to County to the extent not already transferred. In the event of such termination, Contractor shall be entitled to payment for the work performed prior to the termination date, all direct costs associated with the work up to the termination date and the Construction Services Fee for the work performed prior to the termination date at the rate identified in Article 5 of the Agreement. 29. The selection of bidders shall be in accordance with the laws of Colorado. In the event of Contractor's non-compliance with the Colorado labor laws,this Contract may be canceled,terminated or suspended, in whole or in part, without any liability to the County. 30. Contractor acknowledges that the Work is a public work financed in whole or in part by funds of the state of Colorado and/or County, and pursuant to section Title 8-17-101, C.R.S. (1973) Colorado labor shall be employed to perform the Work in the extent of not less than eighty percent(80%) of each type or class of labor in the several classifications of skilled and common labor employed in the Work. For purposes of this provision, Colorado labor" means "any person who is a resident of the state of Colorado at the time of employment, without discrimination as to race, color, creed, sex, age, or religion except when sex or age is a bona fide occupational qualification. 36 31. Contractor agrees to comply with the letter and spirit of the Colorado Anti-discrimination Act of 1957, as amended, and other applicable laws respecting discrimination and unfair employment practices. Pursuant thereto, the following provision shall be contained in all County contracts or subcontracts: during the performance of this Contract, Contractor agrees as follows: A. Contractor will not discriminate against any employee or applicant for employment because of race, creed, color, national origin, sex, marital status, religion, ancestry, mental or physical disability, sexual orientation, or age. Contractor will take affirmative action to insure that applicants are employed and that employees are treated during employment, without regard to the above mentioned characteristics. Such action shall include, but not be limited to,the following: employment, upgrading, demotion or transfer, recruitment or recruitment advertising; lay-offs or terminations; rates of pay or other forms of compensation; and selection for training, including apprenticeship. Contractor agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the contracting officer setting forth provisions of this non-discrimination clause. B. Contractor will, in all solicitations or advertisements for employees placed by or on behalf of Contractor, state that all qualified applicants will receive consideration for employment without regard to race, creed, color,national origin, sex, marital status, religion, ancestry,mental or physical disability, or age. 32. Colorado Statutes do not provide for any right of lien against public buildings. In lieu thereof, Title 38-26-107 ct seq. C.R.S., as amended,provides adequate relief for any claimant having furnished labor, materials, rental machinery, tools, equipment or services toward construction of the particular public work in that final payment may not be made to a Contractor until all such creditors have been put on notice by publication in the public press of such pending payment and given opportunity to stop payment to Contractor in the amount of such claims. 37 rg 61 1 12 11I111ti! 0 A, Jt0 11 i 1 1 II\ I 1 ,I 1 111111 , ' 1 i,''':,; III j fC1 ' ' 1 i;,,, Ttt°,- . 77, , 1 1 1 I 1 I Ai I 1 1 1111111 /N 1)il K /1! Et(, 7:: ii hi Al , 1 \t i\\-AT „11 „ ,. 6e iii i ZU IN di lg I 1I 1 iiimmil111111111:111PP ' '' :!11111111- I , 1.11,L,,,.; .---- 1 5, 1 1 irtik , - _ - 4/1vilii ' ' lilt 111 1 if f 11 ii< 1111-111r 2 cp i-(---- 1 2 1) gZ ge llImill. 47111,71, l' 1 lim1114>: i r--, r t 1 T4 0 I I,1 i Exhibit C" CONSTRUCTION MANAGEMENT (CM) FEE PROPOSAL FORM 1 page) Eagle County Building Roof Replacement Eagle, Colorado August 8th, 2013 RESPONDENT (FIRM NAME): ColWest Roofing Inc. Description Proposal 1. Pre-Construction services Maximum Fees 5,000 2. Construction Services Fixed Fees 18% 3. Construction Change Order Mark-Up 15% 4. Umbrella&General Liability Insurance Rate 2.5% The County represents the Roof Replacement Project Cost is$225,000,which these markups are added to arrive at the Preconstruction Services and Construction Services total cost for construction. The respondent acknowledges and agrees that the above stated fees,mark-ups and schedule (as may be subsequently modified by negotiation) shall become conditions of the Contract Agreement. Name of Authorized Rem :,: .:-> ' i dney Turner Signature:Date:August 8th, 2013 Project Managmentanara'ect MEagle CountyI=411„,._ ty Department P.O.Box 850 Phone: (970)328-8880 414 Eagle,CO 81631 FAX (970)328-3539 3289 Cooley Mesa Road EAGLE COUNTY Gypsum,CO 81637 July 24,2013 ColWest Roofing and Waterproofing 37 County Road 115 Glenwood Springs,Colorado 81601 Re:Eagle County Building Roof Replacement Dear Rodney Turner, Congratulations! We are pleased to inform you that subsequent to your response to Eagle County's Request for Qualifications you are"short-listed"to provide Preconstruction/Construction services for the proposed Eagle County Building Roof Replacement. We require that you submit the information requested on the form provided-Exhibit C-by 2pm August 8, 2013, Submit these via mail,email,or facsimile at any of the following addresses. Mail:PO Box 850 Eagle,Colorado 81631-0850 Physical Address:3289 Cooley Mesa Road Gypsum,CO 81637 Fax:970.328.3546 Email: rick.ullom @eaglecounty.us We have included an Exhibit D to assist in the break down structure of the components to include in the sections of the Exhibit C proposal. A set of the as built roof plans and schematic roof plan documents for the project are attached. Based on our present status of the schematic roof plans there will be a need to include enough time for meeting with the Menendez Architects at their office and/or with Eagle County at my office on a weekly basis from the week of August 19th until the design is completed. It is anticipated the design will be completed the week of September 9`h. Please call Rick Ullom(970.328.8780)with any questions,and thank you for your continued interest in this Project. Sincerely, Rick Ullom,Construction Manager Project Management Department II FEE&SCHEDULE PROPOSAL SPECIAL INSTRUCTIONS Eagle County Building Roof Replacement Eagle,Colorado 1.PROJECT DESCRIPTION The existing natural Vermont slate roof shingles on the building are breaking loose and falling off the roof causing a safety hazard for the public and staff. The slate will be removed and salvaged for resale where possible. We anticipate 50%or more is salvageable. The replacement roofing will be a synthetic slate similar or equal to a product called DaVinci in all existing slate areas except the southern facing slope of two sections of the building complex. These two areas will incorporate photovoltaic solar panels where a standing seam metal roof material will be placed that matches the existing copper standing seam in appearance but will structurally accept solar panel connections. The total estimated area of roofing surface to be replaced is approximately 15,675 square feet. Eagle County Government offices will remain open for business during this project, requiring security, public safety and coordination in scheduling to minimize the project impact on the users of this public facility. There will be active involvement with the design team to determine appropriate water tight solutions for flashing connection shapes and details along with incorporating additional tie off locations for future roof access safety. The schedule for completion of this project is no later than Friday November 1,2013. For the purposes of this proposal assume the direct construction cost of this project to be$225,000 for which the fees Included In Exhibit C will be calculated to determine the total Construction Cost Estimate. Construction of the new roof will include but not be Iimited to the following as determined during design development: 1.Approximately 3800 square feet of roof replacement with a standing seam metal roof material. 2.Approximately 11,875 square feet of roof replacement with DaVinci synthetic slate shingles or equal. 3. High Temperature ice and water shield over the entire roofing surface. 4. Layer of 30 lb.felt. 5. Fabrication and installation of flashing material. 6. Roof tie off locations added at various locations. 7. Demolition and reclamation of the existing slate roof material. 8. Safety barriers and incidental landscaping repair from roof construction access. 2. GENERAL SCOPE OF CONTRACT SERVICES The Contract Services during the Pre-Construction Services include,but are not limited to,field investigation of existing conditions,cost estimating, value engineering,scheduling, logistical planning,constructability analysis,bidding and the submittal of a Guaranteed Maximum Price GMP)proposal for the construction work. The Contract Services during the Construction Services phase include, but are not limited to, construction management,administration,field supervision,coordinating subcontractors, maintaining quality,meeting schedules and providing the general conditions work for the Project. 3. PRE-CONSTRUCTION SERVICES FIXED FEE The Contractor shall participate in the continuing design process as an integral member of the Project Team and shall perform Pre-Construction services that, in general,shall include but not be limited to the following: Attend all necessary work sessions with the Owner and Architect Team to gather and distribute information on the Project as required. In conjunction with the Owner and the Architect, immediately identify the Project requirements and prepare a total Project Budget that properly allocates construction costs and"soft"costs for the various elements of the work intended for the Project. Develop and continue to refine a comprehensive Project Schedule. Identify, set decision dates, and make recommendations to the Owner and the Architect on procurement of long-lead delivery items. Update and monitor the Project Schedule with the Owner and the Architect regularly to identify deviations and changes. Provide field investigations to determine any existing conditions that are needed to properly develop the design details and specifications as needed for the design team. Provide value engineering and life-cycle costing for all materials,equipment and systems mutually agreed upon to determine the best possible value to the Owner. Conduct formal value engineering work sessions with the Owner and the Architect,and recommend design detail alternatives. Prepare and monitor estimates of the construction cost during each of the design phases based on detailed quantity surveys of the Drawings and Specifications. Advise the Owner and the Architect if it appears that the construction budget will not be met,and make recommendations for corrective action. Review the drawings and specifications as they are being prepared, and recommend alternate solutions whenever design details affect budget,schedule,constructability, and consistency with local and traditional trade practice. Recommend and pre-qualify subcontractors and contract suppliers as needed to develop a bidder's list for review and approval by the Owner and the Architect. Initiate negotiations with the approved subcontractors and suppliers when requested. Prepare a detailed approach to phasing of the work, mobilization, logistics, quality control and safety for review and approval by the Owner and Architect. Prepare and submit a final Guaranteed Maximum Price(GMP)Proposal for the Owner's optional acceptance reflecting the entire cost,scope of work and the quality intent of the Project before any construction funds are committed. The GMP Proposal shall be supplemented with a complete and detailed breakdown of costs in an open book sharing of pricing information for the entire Project. All construction costs must be clearly defined and included in the GMP Proposal, and as such, allowances for work scope will not be allowed unless specifically approved by the owner as appropriate. Assist the Owner and the Architect as necessary in interfacing with the Building Department and other authorities having jurisdiction over the Project in order to obtain the building permit(s)on a timely basis for the construction activities. The Pre-Construction Services Fixed Fee shall be stated on the CM Fee Proposal Form("Exhibit C", Item 1)and shall include,as a minimum,the preceding scope of required Pre-Construction Services. Compensation for expenses in connection with the Pre-Construction Services shall be paid in one lump sum with the first construction pay application. In the event the Project or the Contractor's services are cancelled for any reason whatsoever,the Contractor shall be reimbursed for actual verifiable costs incurred during preconstruction phase services up to the amount stated in the Fee Proposal. 4. CONSTRUCTION SERVICES FEE AND GENERAL CONDITIONS COST The Contractor's Construction Services Fixed Fee shall be based in strict accordance with the attached document titled"CM FEE STRUCTURE." This document shall be attached to the formal Contract Agreement and identified as"Exhibit C." All items checked in the second column identified as"CM Basic Fee"shall be included without exception in Construction Services Fixed Fee. It is specifically intended that all General Conditions costs,Construction Management(CM)field overhead costs, and GM's overhead and profit margin shall be included in the Construction Services Fixed Fee. All General Conditions and General Requirements for the Project shall be provided and performed by the CM. Assigning any of these costs to categories that are inconsistent with Exhibit D is not acceptable without prior approval from the Owner. Cost reimbursement will not be allowed for General Conditions or General Requirements unless specifically provided in the"CM FEE STRUCTURE." The Construction Services Fixed Fee shall be stated on the CM Fee& Proposal Form("Exhibit C, Item 2"). Once the Design is completed and the Contractor provides the final accepted Guaranteed Maximum Price this Fee will not be subject to reduction through the efforts of the design team via design refinement,or by the CM via value engineering, procurement savings, accelerated scheduling or other construction efforts saving cost. Abandonment or a significant reduction in the scope or magnitude of the Project would result in a negotiated reduction of the Fee, 5. CONSTRUCTION CHANGE ORDER MARK-UP For Owner directed changes to the scope of the work, the CM shall propose a Percentage Fee for additive change orders to the Guaranteed Maximum Price(GMP)Contract amount. Deductive change orders will be credited only the cost of the work.The Construction Change Order Mark-up shall be stated on the CM Fee Proposal Form("Exhibit C", Item 3). The Owner and the CM/GC shall mutually negotiate any subcontractor and contract supplier change order mark-ups with the various trades after bids have been received. 6. SCHEDULE The final project schedule is not certain at this time; however, it is the Owner's intent to select the Construction Firm by July 19,2013 and to commence Pre-Construction Services immediately. It is anticipated that Construction Services will commence approximately September 3, 2013 and all components will be completed by November 1, 2013. 7. ADDITIONAL PROPOSAL RESPONSE REQUIREMENTS Provide an organizational chart indicating how your firm would staff and structure the proposed team (both in the field and in the office)during the Pre-Construction and Construction phases. Specify on the CM Fee Proposal Form("Exhibit C", Item 5),the percentage rate that you propose for Umbrella and General Liability insurance as per our General Conditions requirements. 8. CONSTRUCTION CONTRACT The Construction Contract will be in the form of Eagle County's,Standard Form of Agreement Between Owner and Contractor where the basis of payment is the Cost of the Work Plus a Fee with a negotiated Guaranteed Maximum Price",with such modifications and additions as are mutually agreeable to the Owner and the Contractor. See Contract and General Conditions provided in this packet. In addition,the Contract Documents will include without limitation: a) The Request for Qualifications Document. b) This CM Fee Proposal Special instructions Document. c) Exhibit A,General Conditions. d) Exhibit B. Plans and Specifications. e) Exhibit C Construction Management Fee Proposal. f) Exhibit D Construction Management Fee Structure g) Addenda,clarifications or attachments to the above, deemed reasonable and necessary by the Owner and Design Firm. h) The Construction Firm's final Guaranteed Maximum Price Proposal once accepted by the Owner. 9. EXCEPTIONS Note any and all exceptions or qualifications to these Special instructions and conditions of the Contract for Construction contemplated for the Project. END Exhibit C" CONSTRUCTION MANAGEMENT(CM)FEE PROPOSAL FORM 1 page) Eagle County Building Roof Replacement Eagle,Colorado August 8th,2013 RESPONDENT(FIRM NAME) Description Proposal 1.Pre-Construction Services Maximum Fees 2.Construction Services Fixed Fee 3. Construction Change Order Mark-Up 4.Umbrella&General Liability insurance Rate The County represents the Roof Replacement Project Cost is$225,000 which these markups are added to arrive at the Preconstruction Services and Construction Services total cost for construction. The respondent acknowledges and agrees that the above stated fees, mark-ups and schedule(as may be subsequently modified by negotiation)shall become conditions of the Contract Agreement. Name of Authorized Representative: Signature: Date: e v w w z m 0 o 3 o `D O D o m w 2 ?) c 7 7- C) 0 CD 0 m - o CONSTRUCTION MANAGEMENT FEE STRUCTURE 0 EAGLE COUNTY BUILDING ROOF REPLACEMENT o EXHIBIT D o R. 3 o JULY 22,2013 D 0 °1 F c) m m3cDCD B 3 N A. PROJECT MANAGEMENT 1.Architectural Consultant Selection x 2. Civil Consultant Selection x 3. Structural Consultant Selection x 4. Mechanical Consultant Selection x 5. Electrical Consultant Selection x 6. Special Consultant Selection x 7. Review Design Concepts x x x 8. Develop Bid Packages x x x 9. Site Use Recommendations x x x 10. Material Selection Recommendations x x 11. Building Systems Recommendations x x 12. Building Equipment Recommendations(Movable) x x 13. Building Equipment Recommendations(Fixed) x x 14. Coordinate Owner-Supplied Fixed Equipment x x x 15. Coordinate Owner-Supplied Movable Equipment x 16. Construction Feasibility Recommendations x 17. Construction Scheduling Recommendations x 18. Life Cycle Costing Analysis x 19. Informal Value Engineering x 20. Formal Value Engineering x 21. Energy Use Analysis&Recommendations x 22. Labor Availability Review(Subcontractors) x 23. Material Availability Review x 24. Equipment Availability Review x 25. Subcontractor Availability Review x 26. Construction Logistical&Execution Plan x 27 Field Investigations x B. PROJECT COST CONTROL 1.Total Project Cost Budget x 2. Construction Cost Budget x x 3. Schematic Design Cost Estimate x 4. Guaranteed Maximum Price Cost Estimate x 5.GMP Proposal x 6. Bid Package Estimates x 7. Construction Cash Flow Projections(Monthly) x 8. Material Surveys&Trade Contractor Estimates x 9. Set-Up Cost Accounting x 10. Set-Up Reporting Methods x 11. Set-Up Payment Procedure x 12. Set-Up Change Order Procedure x 13:Prepare Change Order Cost Estimates x 14. Verify Correctness of Quantities&Prices of All COs x x x 15, Continued Project Cost Monitoring x x C. PROJECT SCHEDULING 1. Preconstruction Activity Schedule(Bar Chart) x 2. Construction Activity Schedule(CPM Set-Up) x 3. Construction Activity Schedule w/Milestones(CPM Updates) x 4.Shop Drawing&Submittal Schedule/Procedure x 5. Mock-Up Schedule&Procedure x 6. Short-Interval Schedules x 7. Occupancy Schedules x D. SUBCONTRACTOR SELECTION/PURCHASING 1. Set Prequalification Criteria x 2. Recommend Subcontractor Selection Methods x 3. Recommend Subcontractor Award Methods x 4. Develop Subcontractor Interest x Page 1 of 6 o C) > v m CO Z N 0 co - K K 0 7 C N O N d •• OCO n N 0Ocn CONSTRUCTION MANAGEMENT FEE STRUCTURE m a EAGLE COUNTY BUILDING ROOF REPLACEMENT m EXHIBIT D 3 ° z CD N x nJULY22,2013 HCD 3 ,-^om To" 3 N 5. Prepare Bidding Schedules x 6. Issue Plans,Specifications&Addenda x 7. Receive Bids x 8.Analyze Bids x 9. Recommend Award x 10. Determine Local Manpower Availability x 11. Prepare Subcontracts&Supplier Contracts x 12. Prepare Change Orders x 13.Verify Correctness of Quantities&Prices of All CO's x 14. Coordinate Owner-Supplied Fixed Equipment x E. CONTRACT DOCUMENT COORDINATION 1. Constructability Review&Recommendations x 2. Responsibility For Temporary Facilities x 3. Review For Jurisdictional Overlap x 4. Review For Inclusion of All Work x 5. Review For Adequately Phased Construction x 6. Identify Long-Lead Items x 7. Identify Commodity Shortages x 8. Review For Installation of Owner Supplied Fixed Equip x 9.Apply For Building Permits x x 10. Obtain Building Permits x x CONSTRUCTION SERVICES F. GENERAL CONTRACTOR OFF-SITE STAFF&SERVICES 1. Corporate Executives x 2. Principal In Charge x 3. Project Executive x 4. Operations Manager x 5. Construction Manager x 6. Project Manager x 7. Project Engineer x 8. Mechanical&Electrical Coordinator x 9. Safety Manager/Field Audit x 10. EEO Officer x 11. Human Resources x 12. Secretarial x 13 Project Estimating x 14 Project Accounting x 15 Project Data Processing x 16 Project Scheduling x 17 Project Purchasing x 18 Basic Legal Services x 19 Home Office Operating Expenses x 20 Benefits for Above Personnel x 21 Vacations for Above Personnel x 22 Bonuses for Above Personnel(If Any) x G. GENERAL CONTRACTOR ON-SITE STAFF&SERVICES 1. Project Manager(s)non labor x 2. Project Superintendent(s)non labor x 3.Assistant Superintendent(s) x 4. Project Engineer(s) x 5. Field Engineer(s) x 6. Mechanical&Electrical Coordinator(s) x 7. Quality Control Engineer(As Required)x 8. Project Assistant/Clerk/Typist(As Required) x 9. Safety Engineer(As Required)x 10. Field Accounting x 11. Data Processing x Page 2 of 6 c1 5 o m m z O 0 N - `G G O 3 c m p D O W d 5 O N O a 3' O N 3 CONSTRUCTION MANAGEMENT FEE STRUCTURE 3 CD ° m EAGLE COUNTY BUILDING ROOF REPLACEMENT m - EXHIBIT D n 3 ° JULY 22,2013 N ut Dr n iD 3 /11 CD m 3 N 12. Field Engineering&Layout x 13. Registered Surveyor(As Required) x 14. Security Guard/Watchman Service x 15. Ground Transportation (As Required) x 16. Airline Transportation (As Required) x 17. Meals&Lodging (As Required) x 18. Personnel Moving&Relocation Expense x 19. Personnel Subsistence Costs x 20. Benefits for Above Personnel x 21.Vacations for Above Personnel x 22. Bonuses for Above Personnel(If Any) x H. DUALITY CONTROL/WARRANTY 1. Implement&Submit Construction Quality Control Plan x 2.Quality Control Responsibility x 3.Quality Control Inspection Responsibility x x 4. Field Inspector x x 5. Inspector's Office x 6. Inspector's Transportation x 7. Inspector's Equipment x 8.Testing&Inspections x x 9. Special Inspection Consultants x 10. Special Testing Consultants x 11, Concrete Testing x 12. Masonry Testing x 13. Compaction Testing x 14. Field Welding&AISC Bolted Connection Testing x 15. Soils Investigations/Geotechnical Reports x 16. Environmental Testing x 17. Environmental Inspection x 18. Environmental Cleanup Coordination/Govt Document x 19. Special Testing Services x 20. Project Progress Photographs x x x 21.Warranty Inspections Coordination x x x 22.Air&Water Balancing x 23. Operator On-Site Training x 24. Prepare Operation Manuals x 25. Prepare Maintenance Manuals x 26. Prepare Preventive Maintenance Manual x 27. Drug Testing&Screening(Field Personnel) x 28. Warranty Inspections Coordination x 29. Warranty Service Cost Reserves x 30. Prepare Punch List(s) x x 31.Approve Punch List(s) x x I. TEMPORARY FACILITIES 1.Temporary Field Office Facility x 2. Field Office Furniture&Equipment x 3. Field Office Copier(s)x 4. Field Office Fax Machine(s) x 5. Field Office Computer(s)&Software x 6. Field Office Supplies x 7. CM Storage Trailers/Sheds x 8. Field Office Equipment Maintenance&Repairs x 9.Architect/Engineer Temporary Office x 10. Project Sign x 11. Directional/Warning Signs x 12. Bulletin Boards x 13. Potable Drinking Water/Ice/Cups x 14.Temporary Toilets/Sanitary Sewer x 15.Temporary Construction Fencing/Safety Fencing x x Page 3 of 6 o C) 5 o W co z O N - K K O O ° ° m o D o y iu f - 3 y C n 0 c S (7 7 N 0 0A CONSTRUCTION MANAGEMENT FEE STRUCTURE 3 CD o, EAGLE COUNTY BUILDING ROOF REPLACEMENT o EXHIBIT D 3 ° z JULY 22,2013 m v, n B 3 A 3 16. Barricades x 17. Covered Walkways Of required) x x 18. Safety Equipment x 19. First Aid Station&Supplies x 20. Handrails/Toe Boards/Opening Protection x 21. Safety Nets x 22. Temporary Stairs x 23. Fire Extinguishers x x 24. Flagman/Traffic Control x x 25. Job Hauling Charges x J. TEMPORARY UTILITIES 1.Temp Telephone Install Equipment&Monthly Fee x 2. Telephone Expense(Long Distance Charges) x 3.Telephone Expense(Internet Charges)x 4. Cellular Phone Charges x 5.Arch/Eng.Telephone Charges(Local Calls) x 6.Temporary Electrical Service/Distribution x 7.Temporary Electrical Wiring&Lighting x 8. Light bulbs&Temp Electrical Maintenance x 9. Electrical Power Consumption Expense x 10. Temporary Water Service/Distribution x 11.Temporary Water Consumption Expense x 12.Temporary Gas Service/Distribution x 13.Temporary Gas Service Consumption Expense x 14. Temporary Heating Service(Permanent System)x K. CLEAN-UP 1. Daily Clean-Up x 2. Final Clean-Up x 3. Final Glass Cleaning x 4. Debris Hauling/Removal x 5.Trash Chutes x x 6. Trash Dumpsters x 7. Dump Permits&Fees x 8. Dust Control x L. WEATHER PROTECTION/TEMPORARY HEATING 1. Remove Snow&Ice(Site) x 2. Remove Snow&Ice(Buildings) x 3.Temporary Enclosures(Buildings) x 4.Temporary Weather Protection for Sub Trades x 5.Temporary Heating Equipment for Sub Trades x 6.,Temporary Field Office Heating Energy Cost x 7. Fuel Cost for Heating(Permanent Heat System) x 8. Permanent Heat System Filter Replacement x 9. Maintenance Cost(Permanent Heat System) x 10.Warranty Cost(Permanent Heat System) x 11. Temporary Heat Energy/Fuel x M. ON-SITE EQUIPMENT/HOISTING 1.Automobile(s)&Fuel x 2. Pick-Up Truck(s)&Fuel x 3.Tires&Maintenance Cost for CM/GC Equipment x 4. Hoisting Equipment&Fuel x 5. Mobile Crane(s) x 6. Material/Personnel Hoist(s) x 7. Crane&Hoist Operator(s)x 8.Temporary Elevator Cab Protection x 9.Temporary Elevator Maintenance Charges x 10._2-Way Radio Equipment x Page 4 of 6 U C7 7 0 m m z A fD O D o °' 3 B3yC f0) n O S n A o 9, 7 o 0 71 D CONSTRUCTION MANAGEMENT FEE STRUCTURE o EAGLE COUNTY BUILDING ROOF REPLACEMENT m EXHIBIT D m < 3 o z JULY 22,2013 m N fD mNCD m 3 N N. SMALL TOOLS&EXPENDABLE SUPPLIES 1. Small Tools(CM only) x 2. Expendable Supplies x O. ECO BUILD REQUIREMENTS 1. MR2.1 Construction Waste Management,Salvage or Recycle 50% x MR2.2 Construction Waste Management,Salvage Additional 25%(if 2. possible) x 3. MR5.1 Local/Regional Materials,20%Manufactured Locally x 4. MR5.2 Local/Regional Materials,10%Harvested Locally x 5. IA03.1 Construction IAQ Management Plan,Construction x 6. IAQ4.1 Low-Emitting Materials,Adhesives&Sealants x 7. IA04.2 Low-Emitting Materials,Paints x 8. IAQ4.3 Low-Emitting Materials,Carpet x 9. IAQ4.4 Low-Emitting Materials,Composite Wood x P. DOCUMENT REPRODUCTION/PRINTING 1. Cost Study Drawings&Specifications x 2. Bid Package Drawings&Specifications x 3. Construction Drawings&Specifications(5 Sets Max.) x 4.Subcontractor/Supplier Prequalification Forms x 5. Bidding Instructions x 6. Postage&Express Delivery Costs x x 7. Subcontract&Supplier Contract Agreement Forms x x 8. Shop Drawing Reproduction x 9. Printing&Duplication Expense(Miscellaneous) x x 10. As-Built Documents(Mark-ups&Recording) x 11. As-Built Documents(Computer Aided Drafting) x 12. As-Built Documents(Printing) x 13. Maintenance Manuals(From Subs) x 14. Operation Manuals(From Subs) x 15. Estimating Forms x x 16. Schedule Report Forms x x 17.Accounting Forms x x 18. Field Reporting Forms x 19. Cost Reporting Forms x 20. Special Forms x x Q. INSURANCE&BONDS 1. Builder's Risk Insurance x 2. Builder's Risk Deductible x 3. Special Insurance-Earthquake x 4. Special Insurance-Fire x 5. Special Insurance-Flood x 6. Special Insurance-Machinery&Equipment x x 7. General Liability Insurance x 8. Umbrella Liability Insurance x 9. Excess Liability Insurance x 10. Completed Products Insurance x 11. Professional Liability Insurance x 12. Workman's Compensation Insurance x 13. FICA/Medicare Insurance(CM/GC's Only) x x x 14. Federal Unemployment Insurance(CM/GC's Only)x x 15. State Unemployment Insurance(CM/GC's Only) x x 16. Performance Bond x 17. Payment Bond x 18. Subcontractor&Supplier Bonds x R. PERMITS&FEES 1. Foundation Permit x Page 5 of 6 c> > v CO m Z A 0 N - G K O o ° ° m O D o !.1. °' °. n 7 y C n n 3 7" n A W O m - O N. W 7 CONSTRUCTION MANAGEMENT FEE STRUCTURE EAGLE COUNTY BUILDING ROOF REPLACEMENT 7 m EXHIBIT D 2 3 ° z o ui 'c nJULY22,2413 N 3 ,To 3 N 2. Superstructure Permit x 3. Building Permit(General) 4. Mechanical Building Permit x 5. Electrical Building Permit x 6. Plan Check Fees 7. Street Use Permit x 8. Curb&Gutter Permit x 9. Sidewalk Permit x 10. Landscape Permit x 11. Street/Curb Design Charge x 12. Sign Permits x 13. Site Drainage Study 14. Site Drainage Permit x 15. Utility Development Fees x 16. Plant Investment Fees x 17. Electrical Primary Construction Fee x 18. Water Service Construction Fee x 19. Gas Service Construction Fee x 20. Water Tap(Inspection)Fee x 21. Sanitary Tap(Inspection)Fee x 22. Storm Tap(Inspection)Fee x 23. Special Tap Fees x 24. Contractors Licenses x 25. Zoning Fees x 26. Construction Equipment Licenses x 27. Construction Equipment Permits x S. OTHER COSTS 1. Sales&Use Taxes(As Required)(EXEMPT) x 2. Construction Labor Costs x 3. Construction Material Costs x 4. Construction Equipment Costs x 5. Cost of Design&Engineering 6.NE Cost for Bid Packages 7, Preliminary Soils Investigation x 8.,Title/Development Cost x 9. Land Costs x 10. Financing/Interest Cost x 11. Interim Financing Costs x 12. Building Operation After Move-In x 13. Building Maintenance After Move-In x 14. FF&E Coordination Services x 15. Owner Moving Transition Manual x 16. Owner Moving Costs x 17 CM Overhead Cost x x x 18 CM Profit x x III Page 6 of 6