Press Alt + R to read the document text or Alt + P to download or print.

No preview available

The URL can be used to link to this page

Home My WebLink AboutC14-306 FCI Constructors First Addendum FIRST ADDENDUM APPROVING THE GUARANTEED MAXIMUM PRICE, BUDGET,AND CONSTRUCTION SCHEDULE FOR THE EAGLE COUNTY REGIONAL AIRPORT SNOW REMOVAL EQUIPMENT FACILITY(SRE) THIS First Addendum is made and entered into this Of). day of August, 2014 between the Board of County Commissioners, County of Eagle, State of Colorado, (hereinafter referred to as "County") and FCI Constructors, Inc. (hereinafter referred to as "FCI"). Together all shall be referred to as"Parties." WHEREAS, County and FCI entered into an Agreement dated December 17, 2013 ("Original Agreement") for Preconstruction and Construction of the Eagle County Regional Airport Snow Removal Equipment Facility;and WHEREAS, the Original Agreement called for the provision by FCI of a proposed Guaranteed Maximum Price (hereinafter referred to as "GMP"),detailed budget and construction schedule to the County; and WHEREAS,the GMP,budget and construction schedule must be approved by the Eagle County Project Manager and the County before FCI may be authorized to commence construction services;and WHEREAS,FCI has presented to the County a GMP,detailed budget and construction schedule attached hereto;and WHERAS, the Eagle County Project Manager and the County wish to approve the GMP, detailed budget and construction schedule as conditioned herein and authorize the issuance of a Notice to Proceed with Construction Services. In consideration of the terms and conditions of the Original Agreement, the sufficiency of which is hereby acknowledged, County and FCI hereby agree to the following: THAT, the GMP, detailed budget and construction schedules attached hereto are hereby accepted by the undersigned and incorporated into the Contract Documents as defined in Article 2.2(A) of the Original Agreement. THAT,Article 12 of the Original Agreement shall be modified with the addition of the following Contract Documents: 12.6 Construction Set drawings dated July 14, 2014;Project Manual specifications dated July 14,2014;Bid Clarifications provided by Menendez Architects on July 21,2014 and July 22,2014. 12.7 First Addendum Approving the Guaranteed Maximum Price, Budget,and Construction Schedule, including attached exhibits or the Eagle County Regional Airport Snow Removal Equipment Facility dated August ,2014. THAT,the Original Agreement, General Conditions, and the Drawings and Specifications shall control if there exists any conflicts with those documents and this First Addendum, including any attachments attached hereto, unless otherwise notified in writing by the Eagle County Project Manager. THAT,FCI is hereby designated as the Construction Manager/General Contractor for the construction of the Eagle County Regional Airport Snow Removal Equipment Facility. THAT,the Eagle County Project Manager is authorized to issue a Notice to Proceed to FCI to perform those Construction Services set forth in the Original Agreement. County and FCI agree that, except as expressly altered, modified and changed in this First Addendum, all terms and provisions of the Original Agreement shall remain in full force and effect,and are hereby ratified and confirmed in all respects as of the date hereof. This First Addendum shall be binding on the parties hereto,their heirs,executors, successors, and assigns. IN WITNESS WHEREOF, the parties have executed this First Addendum on the day and year first above written. _ E COUNTY: c" ATTEST: or,01�►, • •F EAGLE, STATE OF COLORADO a 0 `' I'ugh its BOARD OF COUNTY •. *NERS te Teak Simonton — — I� , -Ryan hairman- I -dTtL„ Clerk to the Board of 514- 1---1S14-100— County Commissioners FCI: Name: S`n.e.K M t40AS Title: U; Pras∎6 e.^.4' G:iBRYANImisc\F'CI ADDENDUM.DOC 2 1 III PROJECT: EAGLE COUNTY REGIONAL AIRPORT - SNOW REMOVAL EQUIPMENT BUILDING (SRE) GYPSUM, COLORADO PREPARED FOR EAGLE COUNTY, COLORADO sat* EAGLE COUNTY FINAL DESIGN GMP-REVISION#1 7/24/2014/UPDATED 7/31/2014 PREPARED BY:FCI Constructors,Inc. , FCI Constructors, Inc. Date: 7/24/2014/UPDATED 7/31/2014 Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW CONCEPT DESIGN ESTIMATE- REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP NOV 26,2013 DIFFERENCE GYPSUM,COLORADO NEW CONSTR. 26,050 NEW CONSTR. 18,777 FINAL DESIGN GMP-REVISION#1 RENOVATION N/A RENOVATION N/A DESCRIPTION TOTAL SF 26,050 TOTAL SF 18,777 TOTAL COST COST/SF TOTAL COST COST/SF NOTES 010000 GENERAL CONDITIONS $ 162,335 $ 623 $ 162,335 $ 8.65 $ - 310000 SITE WORK $ 574,084 $ 22.04 $ 311,934 $ 16.61 $ 262,150 020000 SITEWORK-BUILDING $ 20,157 $ 0.77 $ 215,689 $ 11.49 $ (195,532) 030000 CONCRETE $ 729,552 $ 28.01 $ 694,515 $ 36.99 $ 35,037 040000 MASONRY $ 123,027 $ 4.72 $ 140,958 $ 7.51 $ (17,931) 050000 METALS $ 64,556 $ 2.48 $ 207,115 $ 11.03 $ (142,559) 060000 WOOD&PLASTICS $ 56,206 $ 2.16 $ 49,417 $ 2.63 $ 6,789 070000 THERMAL&MOISTURE PROTECTION $ 226,434 $ 8.69 $ 115,935 $ 6.17 $ 110,499 140 026 5.38 288 108 15.34 148 082 080000 DOORS&WINDOWS $ $ $ $ $ ( ) 090000 FINISHES $ 396,410 $ 15.22 $ 189,559 $ 10.10 $ 206,851 100000 SPECIALTIES $ 14,363 $ 0.55 $ 15,552 $ 0.83 $ (1,189) 110000 EQUIPMENT $ 660 $ 0.03 $ 56,340 $ 3.00 $ (55,680) 120000 FURNISHINGS $ - $ - $ 6,275 $ 0.33 $ (6,275) 130000 SPECIAL CONSTRUCTION $ 844,336 $ 32.41 $ 722,829 $ 38.50 $ 121,507 140000 CONVEYING SYSTEMS $ - $ - $ - $ - 210000 FIRE SUPPRESSION $ 68,900 $ 2.64 $ 77,676 $ 4.14 $ (8,776) 220000 PLUMBING $ 235,623 $ 9.05 $ 255,942 $ 13.63 $ (20,319) 230000 HVAC $ 418,882 $ 16.08 $ 329,470 $ 17.55 $ 89,412 260000 ELECTRICAL $ 326,794 $ 12.54 $ 366,007 $ 19.49 $ (39,213) 270000 LV SPECIAL SYSTEMS $ 20,000 $ 0.77 $ 33,332 $ 1.78 $ (13,332) SUBTOTAL-DIRECT COST $ 4,422,344 $ 169.76 $ 4,238,988 $ 225.75 $ 183,356 PRECONSTRUCTION FEE $ 17,500 $ 0.67 $ 17,500 $ 0.93 $ - 0.00% BID/ESTIMATING CONTINGENCY $ - $ - $ 84,780 $ 4.52 $ (84,780)0.00% GMP/CONSTRUCTION CONTINGENCY $ 88,447 $ 3.40 $ 127,170 $ 6.77 $ (38,723)2.00% BUILDERS RISK INSURANCE $ 5,719 $ 0.22 $ 5,702 $ 0.30 $ 17 GENERAL LIABILITY INSURANCE $ 19,064 $ 0.73 $ 19,008 $ 1.01 $ 56 0.40% PROPERTY SURVEY $ - $ - $ - $ - $ - BY OWNER SOILS INVESTIGATION/GEOTECHNICAL ENGINEERING $ - $ - $ - $ - $ - BY OWNER MATERIALS TESTING/INSPECTION $ - $ - $ - $ - $ - BY OWNER PLANNING APPLICATIONS/PERMIT/PLAN REVIEW FEES $ - $ - $ - $ - $ - BY OWNER BUILDING PERMIT $ - $ - $ - $ - $ - BY OWNER ARCHITECTURAL DESIGN&ENGINEERING(C/S/M&E) $ - $ - $ - $ - $ - BY OWNER FCI PAYMENT/PERFORMANCE BONDS $ 30,129 $ 1.16 $ 30,042 $ 1.60 $ 87 1-YEAR WARRANTY FCI CONSTRUCTION PHASE FEE $ 183,328 $ 7.04 $ 180,928 $ 9.64 $ 2,400 4.00% FCI FEE HOLIDAY ON 1ST$100k N/A $ - $ (4,000) $ (0.21) $ (4,000) FCI CONSTRUCTION PHASE FEE-OVER$4MM BUDGET N/A $ - $ - $ - $ - TOTAL ESTIMATED COST $ 4,766,531 $ 182.98 $ 4,700,118 $ 250.31 $ 58,413 CONCEPTUAL BUDGET/SCOPE ADJUSTMENTS ACCEPTED VALUE ANALYSIS-AS OF JAN 21,2014 $ (742,196) $ (39.53) ADDED SCOPE-NORTH APPARATUS BAYS-ROOF STRUCTURE BACK IN BASE BID $ 158,277 $ 8.43 ADDED SCOPE-NORTH APPARATUS BAYS-2 ADDITIONAL BAYS $ 119,304 $ 6.35 ADDED SCOPE-NORTH APPARATUS BAYS-ENCLOSE&CONDITIONED SPACE $ 418,670 $ 22.30 (TOTAL ESTIMATED CONSTRUCTION COST $ 4,766,531 I$ 182.98 $ 4,654,173 $ 178.66 $ 112,358 BASE BID SCOPE I VALUE ANALYSIS OPTION-FCI SELF-PERFORM CONCRETE I$ (91,668)1 IN/A I I I TOTAL ESTIMATED CONSTRUCTION COST I$ 4,674,863 1 I$ 4,654,173 1 I$ 20,690 1 Confidential-FCI Constructors,Inc. 2 FCI Constructors, Inc. Date: 7/24/2014/UPDATED 7/31/2014 Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) GYPSUM,COLORADO FINAL DESIGN GMP-REVISION#1 BID ALTERNATES ALTERNATE#1-DELETE RADON GAS VENTING SYSTEM-PIPING&FANS. DEDUCT $ (7,500) ALTERNATE#2-ADD STORAGE PLATFORMS IN EQUIPMENT STORAGE BAYS. ADD $ 53,757 ALTERNATE#3-ADD WINDOW COVERINGS. ADD $ 4,067 ALTERNATE#4-REVISE STOREFRONT SYSTEM FROM 6"TO 4.5"FRAMING. DEDUCT $ (1,400) ALTERNATE#5-REVISE DRY PIPE FP SYSTEM TO WET PIPE SYSTEM. DEDUCT $ (9,300) ALTERNATE#6-ADD NITROGEN GENERATOR SYSTEM TO DRY PIPE FP SYSTEM. ADD $ 16,092 1 Confidential-FCI Constructors,Inc. 3 ' FCI Cost Worksheet 7/24/2014/UPDATED 7/31/ Project EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 28,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 310000 SITE WORK 312100 SITE PREPARATION EWING TRUCKING EROSION CONTROL LOGS LF 946.00 $ 3.90 IF $ 378,389 TEMP CONSTRUCTION FENCING LF 600.00 $ 2.50 LF INCLUDED EROSION CONTROL BLANKETS SY 813.22 $ 3.50 SY INCLUDED HYDROSEED/HYDRO MULCH SY 5,699.78 $ 1.15 SY INCLUDED SOIL/EROSION CONTROL-MAINT. LS 1.00 $ 800.00 LS $ 800 STREET CLEANING-HAUL ROAD LS 1.00 $ 2,000.00 LS $ 2,000 SUBTOTAL-SITE PREPARATION S 381,189 312160 SITE DEMOLITION EWING TRUCKING REMOVE FULL DEPTH ASPHALT PAVEMENT SF 450.00 $ 1.00 SF INCLUDED REMOVE EXISTING ASPHALT MILLINGS SF 17,059.00 $ 0.25 SF INCLUDED SAW CUTTING/REMOVE PARTIAL DEPTH ASPHALT PAVEMENT SF 1.00 $ 1.00 SF $ 1,500 REMOVE PIPE BOLLARDS EA 22.00 $ 23.00 EA INCLUDED REMOVE LIGHT POLE&CONCRETE BASE EA 1.00 $ 200.00 EA INCLUDED PROTECTION OF EXISTING PAVEMENT LS 1.00 $ 1,200.00 LS $ 1,200 PROTECTION OF EXISTING UTILTIES LS 1.00 $ 1,500.00 LS $ 1,500 SUBTOTAL-SITE DEMOLITION $ 4,200 312200 MASS EXCAVATION&SITE GRADING EWING TRUCKING $ - INITIAL SURVEY LS 1.00 $ - LS $ 8,000 MOBILIZATION LS 1.00 $ - LS INCLUDED CLEAR/GRUB SITE LS 1.00 $ 2,175.00 LS INCLUDED CUT EXISTING TO PROPOSED MASS EXCAVATION-SITE CUT/FILL GRADES CY 171.00 $ 6.00 CY INCLUDED MASS EXCAVATION-SITE CUT/FILL-PLACE& IMPORT FILL FROM AIRPORT COMPACT STOCKPILE CY 7,927.20 $ 12.85 CY INCLUDED MASS EXCAVATION-REMOVE UNSUITABLE AT BUILDING PAD BUILDING PAD CY 2,666.67 $ 6.00 CY INCLUDED DISPOSE UNSUITABLE MATERIAL BUILDING PAD CY 2,666.67 $ 8.26 CY $ 12,600 FORM BUILDING PAD-FROM AIRPORT STOCKPILE BUILDING PAD CY 5,333.33 $ 12.20 CY INCLUDED SCARIFY&RECOMPACT-SLAB ON GRADE SUB GRADE-12" PREPARE BUILDING SUBGRADE SY 2,424.89 $ 1.80 SY INCLUDED SCARIFY&RECOMPACT-SLAB ON GRADE SUB GRADE-12" PREPARE PAVEMENT SUBGRADES SY 1,723.33 $ 1.80 SY INCLUDED SCARIFY&RECOMPACT-BUILDING PAD SUB PRIOR TO STRUCTURAL FILL SOILS-24" PLACEMENT LS 1.00 $ - LS $ 3,800 ROUGH GRADE SITE-+/-.10 FT SF 115,400.00 $ 0.11 SF INCLUDED GEOSTABILIZATION FABRIC-MIRAFI CONCRETE PAVEMENTS SY 408.22 $ 2.45 SY INCLUDED GEOSTABILIZATIQN FABRIC-MIRAFI ASPHALT PAVEMENT SY 1,408.00 $ 2.45 SY $ 3,450 RE-SPREAD TOPSOIL FROM ON SITE STOCKPILE LS 1.00 $ 2,500.00 LS INCLUDED POT HOLING FOR UTILITIES LS 1.00 $ 2,000.00 LS $ 2,000 LAYOUT HRS 24.00 $ 54.00 HRS $ 1,298 SUBTOTAL-MASS EXCAVATION&GRADING $ 30,946 312610 ASPHALT PAVING ELAM CONSTRUCTION ASPHALTIC CONCRETE PAVING-ON SITE PARKING 6'TH PAVEMENT TN 403.20 $ 128.00 TN $ 75,861 ASPHALTIC CONCRETE PAVING-ON SITE PARKING-BUTT JOINT OVERLAY 2'TH PAVEMENT TN 9.02 $ 140.00 TN INCLUDED FINE GRADE SUBGRADE SY 1,280.00 $ 1.65 SY INCLUDED SOIL STERILANT 1 APPLICATIONS-SUBGRADE SY 1,280.00 $ 0.63 SY $ 800 MATERIAL ESCALATION LS 1.00 $ - LS $ 3,500 SUBTOTAL-ASPHALT PAVING $ 80,161 312616 PAVEMENT BASE MATERIAL EWING TRUCKING CONCRETE PAVEMENT BASE COURSE-CLASS 6 ROAD BASE-6"THICK SNOW MELT APRONS CY 37.78 $ 51.20 CY INCLUDED CONCRETE PAVEMENT BASE COURSE-CLASS 6 ROAD BASE-6"THICK EXTERIOR PAVEMENT CY 38.13 $ 51.20 CY INCLUDED 31000 SITEWORK FCI Constructors,Inc.Confidential Page 4 FCI Cost Worksheet 7/24/2014/UPDATED 7/31/ Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL CONCRETE SIDEWALK BASE COURSE-CLASS 6 ROAD BASE-6"THICK PEDESTRIAN WALKS CY 17.72 $ 51.20 CY INCLUDED ASPHALT PAVEMENT BASE COURSE-CLASS 6 ROAD BASE-6"THICK CY 256.00 $ 51.20 CY INCLUDED SUBTOTAL-PAVEMENT BASE MATERIAL $ 31000 SITEWORK FCI Constructors,Inc.Confidential Page 5 • FCI Cost Worksheet 7/24/2014/UPDATED 7/31/ Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 310000 SITE WORK 312650 STORM SEWER EWING TRUCKING STORM SEWER PIPING-12"RCP LF 210.00 $ 58.80 LF INCLUDED EXTERIOR TRENCH DRAINS LF 90.00 $ 110.00 LF $ 9,900 CONCRETE HEADWALL EA 1.00 $ 3,500.00 EA $ 3,500 STORM CATCH INLET STRUCTURE EA 1.00 $ 3,248.00 EA INCLUDED STORM SEWER MANHOLES N/A-EXCLUDED EA - $ 3,848.00 EA 8 - RIP RAP-24"THICK CY 2.00 $ 71.00 CY INCLUDED SUBTOTAL-STORM SEWER $ 13,400 312660 SANITARY SEWER EWING TRUCKING SANITARY SEWER-4" LF 40.00 $ 51.10 LF INCLUDED SEWER TAP EA 1.00 $ 1,650.00 EA INCLUDED SAND/OIL SEPERATOR W/PLUMBING EA - $ 7,948.00 EA $ - SAN SEWER MANHOLES EA 1.00 $ 3,846.00 EA INCLUDED SUBTOTAL-SANITARY SEWER $ - 312666 WATER SERVICE EWING TRUCKING DOMESTIC/FIRE WATER LINE-6" LF 704.00 $ 55.00 LF INCLUDED DOMESTIC WATER LINE-6" LF 37.00 $ 55.00 LF INCLUDED WATER METER&VAULT EA 1.00 $ 11,300.00 EA $ 11,300 INTO BUILDING-1ST FLANGE FIRE SERVICE ENTRY ABOVE FLOOR EA 1.00 $ 2,850.00 EA $ 2,850 FIRE HYDRANTS EA 2.00 $ 3,821.00 EA INCLUDED SUBTOTAL-WATER SERVICE $ 14,160 9126685 DRY UTILITY WORK TRENCH&BACKFILL-NAT GAS, LS 1.00 $ 9,000.00 LS $ 9,000 SUBTOTAL-DRY UTILITY WORK $ 9,000 312830 FENCING AND GATES TAYLOR FENCE REMOVE C-L FENCING LF 197.00 $ 2.00 LF $ 25,288 REMOVE AUTO OPERATED FENCE GATE EA 1.00 $ 500.00 EA INCLUDED CHAIN-LINK FENCING-7O'HG.'LV N"^^'ZEO SITE PERIMETER LF 110.00 $ 32.00 LF INCLUDED CHAIN-LINK FENCE GATES-.7g=64614 X 25'W MOTOR OPERATED EA 1.00 $ 9,080.00 EA INCLUDED GATE OPERATORS/PROXIMITY READERS RELOCATED EA 1.00 $ 1,028.00 EA INCLUDED TEMPORARY SECURITY FENCE- CHAIN-LINK FENCING-72"H-GALVANIZED INSTALL&TAKEDOWN IF 630.00 $ 25.00 LF $ 15,750 SUBTOTAL-FENCING&GATES $ 41,038 312876 MISCELLANEOUS SITE IMPROVEMENTS BIKE RACKS WA-EXCLUDED EA - $ - EA $ - BENCHES-6'LONG-FURNISH&DEL N/A-EXCLUDED EA - $ - EA $ - TRASH RECEPTACLES-FURN&DEL N/A-EXCLUDED EA - $ - EA $ - SITE FURNITURE-BENCHES N/A-EXCLUDED EA - $ 140.00 EA $ • SITE FURNITURE-TRASH RECEPTACLES N/A-EXCLUDED EA - $ 70.00 EA $ - SITE SIGNS-POST AND PANEL N/A-EXCLUDED EA - $ 175.00 EA $ - SITE FURNITURE-TABLES W/CHAIRS N/A-EXCLUDED EA - $ 1540.00 EA $ - SITE MONUMENT SIGN N/A-EXCLUDED EA - $ 12,000.00 EA $ - SUBTOTAL-MISC.SITE IMPROVEMENTS $ - 312900 LANDSCAPING&IRRIGATION LANDSCAPING EXCLUDED SF - $ 5,500.00 SF $ - SUBTOTAL-LANDSCAPING&IRRIGATION $ - 31000 SITEWORK FCI Constructors,Inc.Confidential Page 6 FCI Cost Worksheet 7/24/2014/UPDATED 7/31/ Project EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 310000 SITE WORK-TOTALS $ 574,084 31000 SITEWORK FCI Constructors,Inc.Confidential Page 7 • FCI Cost Worksheet 7/24/2014/UPDATED 7/: Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 020000 SITE WORK(BUILDING) 022200 EXCAV.&BACKFILL&COMPACT EW/NG TRUCKING PLACE/COMPACT DRAINAGE FILL UNDER SLAB-6" BUILDING SLABS CY 484.98 $ 49.00 CY INCLUDED PLACE/COMPACT DRAINAGE FILL TO CRAWL SPACE-4" CRAWL SPACE CY 52.70 $ 49.00 CY INCLUDED FINE GRADE SUBQRADE BUILDING SLABS SF 21,824.00 $ 0.62 SF INCLUDED 15 MIL VAPOR BARRIER N/A SF 24,006.40 $ 0.37 SF $ - SCARIFY&RECOMPACT-SUB GRADE-12" BUILDING SLABS SY 2,424.89 $ 1.95 SY INCLUDED PLACE/COMPACT DRAINAGE FILL TO CRAWL SPACE-4" CRAWL SPACE CY 52.70 $ 49.00 CY $ 2,582 EXCAVATE FOUNDATIONS-MACHINE OVER-EX BUILDING FNDS CY 1,470.00 $ 8.50 CY INCLUDED BACKFILL FOUNDATIONS-IMPORT MATL N/A CY - $ 51.20 CY $ - BACKFILL FOUNDATIONS-NATIVE MAT'L FROM ON SITE STOCKPILE CY 1,470.00 $ 14.20 CY INCLUDED DISPOSE EXCESS MATERIAL OVER-EX BUILDING FNDS CY - $ 10.26 CY $ - EXCAVATE FOUNDATIONS-MACHINE CRAWL SPACE CY 760.00 $ 8.50 CY INCLUDED DISPOSE EXCESS MATERIAL CRAWL SPACE CY 760.00 $ 10.26 CY INCLUDED LAYOUT/COORDINATION-FDN EX/BF HRS 80.00 $ 54.00 HRS $ 4,320 MEMBRANE LINER-CRAWL SPACE FLOOR& WALLS-10 MIL POLYOLEFIN RADON GAS BARRIER SF 5,405.40 $ 1.43 SF $ 7,730 TOTAL-EXCAVATION,BACKFILL&COMPACT $ 14,632 026150 FOUNDATION DRAINAGE SYSTEM EWING TRUCKING PERIMETER FOUNDATION DRAINS-4"DIA LF 350.00 $ 15.25 LF INCLUDED PERIMETER FOUNDATION DRAINS-4"DIA NON-PERF-DAYLIGHTED LF 250.00 $ 22.10 LF $ 5,525 UNDERSLAB DRAINS-4"PERF PIPING N/A-EXCLUDED LF - $ 12.50 LF $ - TOTAL-FOUNDATION DRAINAGE SYSTEM $ 5,526 2000 SITE WORK(BUILDING)-TOTALS $ 20,157 2000 SITEWORK-BLDG FCI Constructors,Inc.Confidential Page 8 • FCI Cost Worksheet 7/24/2014/UPDATED 7/: Project; EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 030000 CONCRETE 033000 CAST-IN-PLACE CONCRETE FCI CONSTRUCTORS COLUMN FOOTINGS APPARATUS BAYS FORM/STRIP COLUMN FOOTINGS SF 1201.00 $ 7.67 SF $ 662,280 SET COLUMN ANCHOR BOLTS SETS - $ 66.00 SETS $ - GROUT COLUMN BASE PLATES EA - $ 42.00 EA $ - REBAR TO COLUMN FOOTINGS TN 6.30 $ 1,806.00 TN INCLUDED CONCRETE TO COLUMN FOOTINGS CY 124.14 $ 184.50 CY INCLUDED SUBTOTAL-COLUMN FOOTINGS $ 652,290 $ 5,254.47 CY WALL FOOTINGS FORM/STRIP WALL FOOTINGS SF 1,994.00 $ 6.15 SF INCLUDED SHEAR KEYWAY-WALL FOOTINGS N/A LF - $ 2.60 LF $ - WATERSTOP-BENTONITE N/A LF - $ 5.20 LF $ - REBAR TO WALL FOOTINGS TN 2.70 $ 1,680.00 TN INCLUDED CONCRETE TO WALL FOOTINGS 4000 PSI CY 77.10 $ 177.87 CY INCLUDED SUBTOTAL-WALL FOOTINGS $ - $ - STEM WALLS ADMIN WING FORM/STRIP STEM WALLS SF 5,032.00 $ 8.50 SF INCLUDED SET EMBED INSERTS FOR JOIST LEDGER ANGLES N/A EA - $ 63.00 EA $ - FORM/STRIP SHELF FOR CF LEDGER JSTS LF 102.00 $ 7.00 LF INCLUDED SET COLUMN ANCHOR BOLTS SETS - $ 66.00 SETS $ - GROUT COLUMN BASE PLATES EA - $ 47.08 EA $ - REBAR TO STEM WALLS TN 4.60 $ 1,510.00 TN INCLUDED POINT&PATCH STEM WALLS SF 2,516.00 $ 0.62 SF INCLUDED CONCRETE TO STEM WALLS 4000 PSI CY 65.60 $ 184.50 CY INCLUDED SUBTOTAL-STEM WALLS $ - $ - STEM WALLS APPARATUS BAYS FORM/STRIP STEM WALLS SF 4,605.00 $ 8.50 SF INCLUDED SET COLUMN ANCHOR BOLTS SETS 22.00 $ 66.00 SETS INCLUDED GROUT COLUMN BASE PLATES EA 22.00 $ 47.08 EA $ 1,036 REBAR TO STEM WALLS TN 5.92 $ 1,510.00 TN INCLUDED POINT&PATCH STEM WALLS SF 2,302.50 $ 0.62 SF INCLUDED RUB FINISH TO EXPOSED WALLS SF 1,792.00 $ 2.16 SF INCLUDED 3/4"CHAMFER EDGE-PILLASTERS LF 176.00 $ 4.55 LF INCLUDED CONCRETE TO STEM WALLS 4000 PSI CY 73.00 $ 184.50 CY INCLUDED SUBTOTAL-STEM WALLS $ 1,036 $ 14.19 TIE BEAMS EXCLUDED-NOT SHOWN FORM/STRIP TIE BEAMS SF - $ 7.00 SF $ - REBAR TO TIE BEAMS ALLOW 12.0011/LF TN - $ 1,806.00 TN $ - POINT&PATCH TIE BEAMS SF - $ 0.62 SF $ - CONCRETE TO TIE BEAMS CY - $ 184.50 CY $ - SUBTOTAL-TIE BEAMS $ - #DIV/01 3000 CONCRETE FCI Constructors,Inc.Confidential Page 9 FCI Cost Worksheet 712412014 I UPDATED 7I Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 030000 CONCRETE 033000 CAST-IN-PLACE CONCRETE FCI CONSTRUCTORS SLAB ON GRADE-8.00"TH APPARATUS BAYS CONCRETE TO SLAB ON GRADE CY 557.50 $ 178.65 CY INCLUDED CONSTRUCTION JOINTS LF 492.00 $ 5.40 LF INCLUDED EDGE FORMS-12" PERIMETER DOOR SILLS LF 158.00 $ 5.70 LF INCLUDED PERIMETER JOINT FILLER-8"X 1/2" LF 619.00 $ 6.85 LF INCLUDED REBAR TO SLAB ON GRADE-2 LAYER45'S AT 12"OC TN 51.92 $ 1,806.00 TN INCLUDED REBAR TO SLAB ON GRADE-CORNER BARS AT COLUMNS TN 0.33 $ 1,806.00 TN INCLUDED REBAR TO SLAB ON GRADE-AT TRENCH DRAINS ALLOW 12#/LF TN 0.38 $ 1,806.00 TN INCLUDED CONSTRUCTION JOINT DOWELS EA 492.00 $ 7.70 EA INCLUDED CONSTRUCTION JTS-WATERSTOP LF 492.00 $ - LF $ 6,150 6"VOID FORMS N/A-EXCLUDED SF - $ 5.25 SF $ - CONTROL JOINTS-SAWN/CAULKED LF 976.00 $ 2.15 LF INCLUDED TROWEL FINISH SLAB ON GRADE SF 20,158.00 $ 0.42 SF INCLUDED CURE&PROTECT SLAB ON GRADE SF 20,158.00 $ 0.41 SF INCLUDED FORM COLUMN POCKETS EA 22.00 $ 54.00 EA INCLUDED GROUT COLUMN POCKETS EA 22.00 $ 38.82 EA INCLUDED SUBTOTAL-SLAB ON GRADE $ 6,150 $ 0.31 SF SLAB ON GRADE-5.00"TH CONCRETE TO SLAB ON GRADE CY 27.98 $ 178.65 CY INCLUDED CONSTRUCTION JOINTS LF - $ 5.40 LF $ - EDGE FORMS-12" N/A LF - $ 5.70 LF $ - PERIMETER JOINT FILLER-6"X 1/2" LF 232.00 $ 5.75 LF INCLUDED REBAR TO SLAB ON GRADE-1 LAYER45'S AT 12"OC TN 2.14 $ 1,806.00 TN INCLUDED CONSTRUCTION JOINT DOWELS N/A EA - 5 7.70 EA $ - 6"VOID FORMS N/A-EXCLUDED SF - $ 5.25 SF $ - CONTROL JOINTS-SAWN/CAULKED LF 256.95 $ 2.15 LF INCLUDED TROWEL FINISH SLAB ON GRADE SF 1,713.00 $ 0.42 SF INCLUDED CURE&PROTECT SLAB ON GRADE SF 1,713.00 $ 0.41 SF INCLUDED FORM COLUMN POCKETS N/A EA - $ 54.00 EA $ - GROUT COLUMN POCKETS N/A EA - $ 38.82 EA $ - SUBTOTAL-SLAB ON GRADE $ - $ - SF ADMIN WING-OVER CRAWL SLABS ON METAL DECKING SPACE CONCRETE TO SLABS ON DECK NORMAL WI-CONCRETE CY 29.66 $ 184.50 CY INCLUDED WIRE MESH REINF.-6X6AN2.1 SF 4,004.00 S 0.89 SF INCLUDED REBAR TO SLABS ON DECK N/A TN - $ 1,806.00 TN $ - WELDED BARS-TO POUR STOP-#4 X 2'6"L N/A-EXCLUDED EA - $ 46.00 EA $ - TROWEL FINISH SLABS ON DECK SF 3,640.00 $ 0.61 SF INCLUDED CURE&PROTECT SLABS ON DECK SF 3,640.00 5 0.33 SF INCLUDED SUBTOTAL-SLABS ON METAL DECKING $ - $ - SF EXTERIOR APRON PAVEMENT 6"THICK CONCRETE TO SLABS ON GRADE 6"THICKNESS CY 33.37 $ 213.85 CY INCLUDED ADD FOR FIBERMESH REINFORCING N/A CY - $ 9.00 CY $ - FINE GRADE SUBGRADE SF 1,716.00 $ 0.32 SF INCLUDED EDGE FORMS-6" LF 127.00 $ 7.00 LF INCLUDED REBAR TO CONCRETE PAVMNT45 BARS AT CONNECTION TO EX PVMNT TN 0.12 $ 1,806.00 TN INCLUDED WIRE MESH REINF.-6X6IW2.9 REINFORCED PANEL SF 198.00 $ 1.18 SF INCLUDED CONSTRUCTION JOINTS LF 288.00 $ 5.40 LF INCLUDED CONSTRUCTION JOINT DOWELS EA 288.00 $ 10.20 EA INCLUDED CONTROL JOINTS-SAWN/CAULKED LF 288.00 $ 3.41 LF $ 3,200 FINISH 6"CONCRETE PAVEMENT SF 1,716.00 $ 0.52 SF INCLUDED CURE&PROTECT CONC PAVEMENT SF 1,716.00 $ 0.41 SF INCLUDED 3000 CONCRETE FCI Constructors,Inc.Confidential Page 10 FCI Cost Worksheet 7124/20141 UPDATED 7/: Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL SUBTOTAL-EXTERIOR APRON PAVEMENT $ 3,200 $ 1.86 SF 3000 CONCRETE FCI Constructors,Inc.Confidential Page 11 FCI Cost Worksheet 7/24/2014/UPDATED 7f Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 030000 CONCRETE 033000 CAST-IN-PLACE CONCRETE FCI CONSTRUCTORS SNOW MELT APPROACH APRONS 6"THICK CONCRETE TO SLABS ON GRADE 6°THICKNESS CY 33.06 $ 213.85 CY INCLUDED ADD FOR FIBERMESH REINFORCING N/A CY - $ 9.00 CY $ - FINE GRADE SUBGRADE SF 1,700.00 $ 0.32 SF INCLUDED EDGE FORMS-8" LF 173.00 $ 4.90 LF INCLUDED REBAR TO CONCRETE PAVMNT45Q12"OC N/A TN - $ 1,806.00 TN $ - CONSTRUCTION JOINTS LF 225.00 $ 5.40 LF INCLUDED CONSTRUCTION JOINT DOWELS EA 225.00 $ 10.20 EA INCLUDED FINISH 6"CONCRETE PAVEMENT SF 1,700.00 $ 0.52 SF INCLUDED CURE&PROTECT CONC PAVEMENT SF 1,700.00 $ 0.41 SF INCLUDED 2"RIGID INSULATION SF 1,700.00 $ 2.20 SF $ 3,740 SUBTOTAL-SNOW MELT APRONS $ 3,740 CONCRETE WALKS-6"THICK ON SITE WALKS CONCRETE TO SIDEWALKS CY 15.51 $ 213.85 CY INCLUDED ADD FOR FIBER MESH REINFORCING N/A CY - $ 11.00 CY $ - ADD FOR COLORED CONCRETE N/A-EXCLUDED CY - $ 90.00 CY $ - REBAR TO SIDEWALKS-#4 BARS AT 16" OC/EW 1.20/i/SF TN 0.48 $ 1,995.00 TN $ 600 FINE GRADE SUBGRADE SF 797.50 $ 0.30 SF INCLUDED EDGE FORMS-6" LF 133.00 $ 6.55 LF INCLUDED EXPANSION JOINTS LF 39.88 $ 8.50 IF INCLUDED SCORE JOINTS LF 159.50 $ 1.93 LF INCLUDED FINISH SIDEWALKS SF 797.50 $ 0.58 SF INCLUDED CURE&PROECT SF 797.50 $ 0.26 SF INCLUDED 2"RIGID INSULATION SF 797.50 $ 2.20 SF $ 1,755 SUBTOTAL-SIDEWALKS $ 2,355 CONCRETE VEE PANS PARKING LOTS SF 304.00 CONCRETE TO SLABS ON GRADE CY 7.92 $ 213.85 CY INCLUDED ADD FOR FIBERMESH REINFORCING N/A CY - $ 9.60 CY $ - FINE GRADE SUBGRADE SF 304.00 $ 0.32 SF INCLUDED EDGE FORMS-6" LF 160.00 $ 7.00 IF INCLUDED REBAR TO CONCRETE PAVMNT45€1212"OC EW N/A-UNREINFORCED TN - $ 1,730.00 TN $ - FINISH 6"CONCRETE PAVEMENT SF 304.00 $ 0.69 SF INCLUDED CURE&PROTECT CONC PAVEMENT SF 304.00 $ 0.41 SF INCLUDED SUBTOTAL-VEE PANS $ - TRENCH DRAINS-CONCRETE ENCASEMENT SURROUND FORM/STRIP SIDE WALLS LF 267.00 $ 9.20 LF INCLUDED REBAR TO TRENCH DRAINS TN 0.45 $ 1,995.00 TN INCLUDED CONCRETE TO TRENCH DRAINS CY 8.16 $ 233.35 CY INCLUDED SUBTOTAL-TRENCH DRAINS $ - $ - LF MEP EQUIPMENT PADS/MISC CONCRETE HOUSEKEEPING PADS LS 1.00 $ 2,100.00 LS $ 2,100 SET/GROUT PIPE BOLLARDS AROUND BUILDING EA 16.00 $ 258.00 EA INCLUDED SET/GROUT PIPE BOLLARDS N/A EA - $ 256.00 EA $ - SUBTOTAL-MEP EQUIPMENT PADS/MISC CONCRETE $ 2,100 3000 CONCRETE FCI Constructors,Inc.Confidential Page 12 FCI Cost Worksheet 7/24120141 UPDATED 71: Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 3000 CONCRETE FCI Constructors,Inc.Confidential Page 13 FCI Cost Worksheet 7/24/2014/UPDATED 71: Project EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 030000 CONCRETE 033000 CAST-IN-PLACE CONCRETE FCI CONSTRUCTORS CONCRETE PUMPING/HOISTING CONCRETE PUMP DYS 5.00 $ 1,800.00 DYS INCLUDED WINTER CONCRETE BUILDING FLATWORK CY 615.14 $ 24.00 CY $ 28,600 WINTER PROTECTION-BLANKETS LS 1.00 $ 12,180.00 LS $ 12,180 LAYOUT/COORDINATION-CONCRETE HRS 173.00 $ 54.00 HRS $ 9,342 CLEANUP FIRS 160.00 $ 41.00 FIRS $ 6,560 DUMPSTERS PULLS 2.00 $ 1,000.00 PULLS$ 2,000 SUBTOTAL-CONCRETE PUMPING/HOISTING $ 58,682 SUBTOTAL-CAST4N-PLACE CONCRETE $ 729,552 030000 CONCRETE-TOTALS $ 729,552 3000 CONCRETE FCI Constructors,Inc.Confidential Page 14 FCI Cost Worksheet 7/24/2014/UPDATED 7/3 Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 040000 MASONRY 042010 UNIT MASONRY BERICH MASONRY 8"CMU WALLS-REINFORCED INTERIOR WALLS SF 3,084.00 8"HOLLOW CMU-SMOOTH FACE PC 3,180.60 $ 10.62 PC $ 104,000 8"BOND BEAM CMU-SMOOTH FACE PC 366.00 $ 11.29 PC INCLUDED MORTAR CY 6.50 $ 300.00 CY INCLUDED VERTICAL REINF.STEEL-8"PTNS LB 1,850.40 $ 0.82 LB INCLUDED ADD FOR GROUTING 8"'WALLS. SF 3,084.00 $ 1.30 SF INCLUDED SCAFFOLDING SF 3,084.00 $ 0.80 SF INCLUDED TOOL JOINTS SF 3,084.00 $ 0.15 SF INCLUDED 8"DUROWALL REINFORCING-16"OC LF 2,467.20 $ 0.24 LF INCLUDED BOND BEAM REINF.STEEL-2 65'S LB 1,160.00 $ 0.82 LB INCLUDED $ 33.72 SF EXTERIOR WALLS--4°SPLIT FACE 4"SPLIT FACE CMU VENEER- VENEER"""" RUNNING BOND SF 2,805.00 EXTERIOR 4"SPLIT FACE CMU WALL VENEER RUNNING BOND PC 3,225.75 $ 9.21 PC INCLUDED MORTAR-COLORED CY 11.06 $ 450.00 CY INCLUDED SCAFFOLDING SF 2,805.00 $ 1.00 SF INCLUDED WALL ANCHORS EA 1,050.56 $ 0.55 EA INCLUDED 4"DUROWALL REINFORCING-16"OC LF 1,275.20 $ 0.24 LF INCLUDED WALL FLASHING-MEMBRANE LF 456.00 $ 5.00 LF INCLUDED INSTALL SHEET METAL FLASHING-FBO LF 228.00 $ 6.00 LF INCLUDED SOLID SF CMU SILL TRIM LF 47.00 $ 19.50 LF INCLUDED SET LOOSE LINTELS-SMALL EA 1.00 $ 30.00 EA INCLUDED SET LOOSE LINTELS-LARGE N/A EA - $ 66.00 EA $ - TOOL JOINTS-CMU SF 2,805.00 $ 0.15 SF INCLUDED WASHDOWN WALLS SF 2,805.00 $ 0.20 SF INCLUDED 4"DUROWALL REINFORCING-16"OC LF 2,244.00 $ 0.20 LF INCLUDED $ • SF 4"CMU WALLS-REINFORCED CMU FOUNDATION VENEER SF 626.00 4"HOLLOW CMU-SMOOTH FACE PC 718.75 $ 8.37 PC INCLUDED MORTAR CY 1.32 $ 300.00 CY INCLUDED ADD FOR GROUTING 4"'WALLS. SF 625.00 $ 1.30 SF INCLUDED SCAFFOLDING SF 625.00 $ 0.80 SF INCLUDED TOOL JOINTS SF 625.00 $ 0.15 SF INCLUDED $ - SF LAYOUT HRS 40.00 $ 54.00 HRS $ 2,160 CLEANUP HRS 80.00 $ 39.00 HRS $ 3,120 DUMPSTERS PULLS 1.00 $ 1,000.00 PULL $ 1,000 I WINTER PROTECTION MO 1.00 $ 6,747.00 /MO $ 6,747 TEMPORARY HEAT-MASONRY WORK MO 1,00 $ 6,000.00 /MO $ 6,000 SUBTOTAL-UNIT MASONRY $ 123,027 040000 MASONRY-TOTALS $ 123,027 4000 MASONRY FCI Constructors,Inc.Confidential Page 15 FCI Cost Worksheet 7/2412014/UPDATED 7/ Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 050000 METALS 053100 METAL DECKING PEAK INTERIORS FLOOR DECK-0.60"22 GA-G60 COATING 1ST FLOOR SF 4,004.00 $ 2.30 SF $ 33,490 ROOF DECK-0.60"22 GA-G60 COATING ADMIN ROOF SF 6,371.20 $ 2.30 SF INCLUDED 20 GA METAL POUR STOP LF 555.00 $ 5.23 LF INCLUDED 2"X 2"-18 GA ROOF DECK SUPPORT LF 372.00 $ 5.33 LF INCLUDED SUBTOTAL-METAL DECKING $ 33,490 054400 COLD-FORMED METAL FRAMING PEAK INTERIORS 12"-12 GAGE FLOOR JOISTS HORIZONTAL FRAMING LF 2,846.80 $ 9.85 LF INCLUDED 12"-12 GAGE ROOF JOISTS LF 5,062.20 $ 10.60 LF INCLUDED 12"-16 GAGE FLOOR JOIST LEDGERS LF 99.00 $ 6.20 LF INCLUDED 12"-12 GAGE JOIST BLOCKING-FLOORS EA 225.00 $ 18.78 EA INCLUDED 12"-12 GAGE JOIST BLOCKING-ROOF EA 515.00 $ 18.78 EA INCLUDED JOIST BLOCKING ATTACHMENT CLIPS EA 1,480.00 $ 2.45 EA INCLUDED FLOOR/ROOF JOIST HANGERS/CONNECTORS EA 910.80 $ 3.25 EA INCLUDED 22 GA METAL SHEAR WALL SHEATHING SF 608.00 S 3.48 SF INCLUDED 4"-20 GAGE MTL TRACK CRAWL SPACE KNEE WALLS LF 612.00 $ 6.75 LF INCLUDED 4"-18 GAGE MTL STUD FRAMING CRAWL SPACE KNEE WALLS LF 918.00 $ 5.15 LF INCLUDED SUPERVISION HRS 173.00 $ 68.00 HRS INCLUDED MISC FASTENERS/EQUIPMENT/SMALL TOOLS LS 1.00 $ 7,500.00 LS INCLUDED SUBTOTAL-COLD-FORMED METAL FRAMING $ - 055010 MISCELLANEOUS METALS PIPE BOLLARDS-8"DIA-GALVANIZED FURNISH ONLY EA 16.00 $ 210.00 EA $ 3,360 WF ROOF FRAMING X-FER BEAM TNS 0.73 $ 6,000.00 TNS $ 4,373 LEDGER ANGLE 6 X 4 X 0.315 ANGLES TNS 1.17 $ 6,500.00 TNS $ 7,613 POUR STOP ANGLE-EXP BOLTED TO CONC 3.5X2.5X0.1875 LF 16.00 $ 27.00 LF $ 432 ROOF ACCESS LADDER-WALL MID- ALUMINUM LF 15.00 $ 135.00 LF $ 2,025 TRENCH DRAIN GRATINGS&LEDGER ANGLES N/A-SEE PREFAB UNITS SF - $ 45.00 SF $ • ANCHOR BOLTS FOR PEMB COLS MAIN BUILDING SETS 23.00 $ 140.00 SETS $ 3,220 STEEL LINTELS AT CMU OPENINGS LF 42.50 $ 13.85 LF $ 689 MISC CLIPS,ATTACHMENTS,HW SF 26,050.00 $ 0.28 SF $ 7,294 LAYOUT HRS 40.00 $ 54.00 HRS $ 2,160 SUBTOTAL-MISCELLANEOUS METALS $ 31,066 050000 METALS-TOTALS $ 64,556 COST PER SF $ 2.48 050000 METALS BID ALTERNATE#2 055010 MISCELLANEOUS METALS CATWALKS GRATINGS-GALVANIZED STORAGE PLATFORM SF 1,035.00 $ 15.75 SF $ 16,301 SUPPORT FRAMING-PRIME PAINTED STORAGE PLATFORM LBS 15,142.00 $ 2.01 LBS $ 30,473 SUBTOTAL-MISCELLANEOUS METALS $ 46,775 5000 METALS FCI Constructors,Inc.Confidential Page 16 FCI Cost Worksheet 7124120141 UPDATED 71 Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL III 5000 METALS FCI Constructors,Inc,Confidential Page 17 FCI Cost Worksheet 7/2412014/UPDATED 713 Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 060000 WOOD&PLASTICS 061100 ROUGH CARPENTRY FCI CONSTRUCTORS ROOF BLOCKING-2"X 4"TREATED NAILERS PERIMETER NAILERS LF 83.60 $ 3.65 LF $ 305 3/4"TH EXTER PLYWOOD-COPING ASSEMBLIES 2-LAYERS SF 906.00 $ 3.28 SF $ 2,967 2"X 6"X 8"COPING BLOCKS UNDER PLYWOOD EA 80.00 $ 8.25 EA $ 680 1/2"TH EXTER PLYWOOD SHEATHING-BACK SIDE OF PARAPETS N/A-SEE DRYWALL SF - $ 2.10 SF $ - EXTERIOR WALL BLOCKING-2.5 X 2.5 IN-WALL NAILER LF 177.10 $ 7.20 LF $ 1,276 EXTERIOR WALL BLOCKING-2.5 X 3.0 IN-WALL NAILER LF 33.00 $ 7.40 LF $ 244 EXTERIOR WALL BLOCKING AT ROOF SCUPPER LF 14.00 $ 9.50 LF $ 133 INTERIOR WALL STRAPPING/BLOCKING- MILLWORK/CASEWORK LF 204.60 $ 5.00 LF $ 1,023 ROUGH TIMBER FRAMING-4"X 6" ROOF CANOPY COLUMNS LF 60.00 $ 21.50 IF $ 1,290 ROUGH TIMBER FRAMING-8"X 10" ROOF CANOPY BEAMS LF 30.80 $ 35.69 LF $ 1,099 ROUGH TIMBER FRAMING-8"X 12" ROOF CANOPY BEAMS LF 48.40 $ 44.81 LF $ 2,169 ROUGH TIMBER FRAMING-8"X 14" ROOF CANOPY BEAMS LF 49.50 $ 50.24 LF $ 2,487 TIMBER FRAMING CONNECTORS EA 20.00 $ 85.00 EA $ 1,700 2"X 6"T&G WOOD DECKING ROOF CANOPIES LF 537.60 $ 4.45 LF $ 2,392 ROUGH HARDWARE LS 1.00 $ 1,500.00 LS $ 1,500 LAYOUT HRS 24.00 $ 54.00 HRS $ 1,298 SUBTOTAL-ROUGH CARPENTRY $ 20,541 064010 MILLWORK DELTA CABINET LAVATORY COUNTERS-QUARTZ LF 15.50 $ 177.00 LF $ 34,095 WALL MOUNTED COUNTER-PLAS LAM LAUNDRY RM IF 5.00 $ 70.00 LF INCLUDED BASE CABINETS-PLAS LAM STAFF BREAK RM LF 12.00 $ 233.56 LF INCLUDED COUNTERTOPS-SOLID SURFACE STAFF BREAK RM LF 12.00 $ 141.71 IF INCLUDED WALL CABINETS-P LAM STAFF BREAK RM LF - $ 213.56 LF $ - 36"W FULL HT STORAGE CABINETS-PLAS LAM STAFF BREAK RM EA 1.00 $ 478.24 EA INCLUDED BASE CABINETS-PLAS LAM TRAINING ROOM LF 15.50 $ 233.56 LF INCLUDED COUNTERTOPS-QUARTZ TRAINING ROOM LF 16.00 $ 176.71 LF INCLUDED WALL CABINETS-P LAM TRAINING ROOM IF - $ 213.56 LF $ - BASE CABINETS-PLAS LAM PRINTING ROOM LF 16.00 $ 233.56 LF INCLUDED COUNTERTOPS-QUARTZ PRINTING ROOM LF 16.00 $ 176.71 LF INCLUDED WALL CABINETS-P LAM PRINTING ROOM LF 17.00 $ 213.56 LF INCLUDED MISC MILLWORK-ALLOW ALLOWANCE SF 5,235.00 $ 0.30 SF $ 1,571 SUBTOTAL-MILLWORK $ 35,666 060000 WOOD&PLASTICS-TOTALS $ 66,206 COST PER SF $ 2.16 I 6000 WOOD&PLASTICS FCI Constructors,Inc.Confidential Page 18 FCI Cost Worksheet 7/24/2014/UPDATED 7/3 Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 070000 THERMAL&MOISTURE PROTECTION 071600 DAMPPROOFING DAMPPROOF PERIM STEM WALLS OUTSIDE FACE OF PERIM FDN SF 1,335.00 $ 1.74 SF $ 2,321 DAMPPROOFING-PROTECTION BD SF 1,335.00 $ 1.25 SF $ 1,669 PERIMETER FOUNDATION INSULATION-1"TH SF 514.00 $ 1.74 SF $ 894 PERIMETER FOUNDATION INSULATION-2"TH SF 3,265.00 $ 2.61 SF $ 8,522 PERIMETER FOUNDATION INSULATION-2"TH- UNDER SLAB N/A-EXCLUDED SF - $ 2.61 SF $ - SUBTOTAL-DAMPPROOFING $ 13,405 071800 WATERPROOFING WATERPROOF CRAWL SPACE FOUNDATION COLD FLUID APPLIED+ WALLS INSULATED DRAINAGE BAORDS SF 1,694.00 $ 8.17 SF $ 13,834 SUBTOTAL-WATERPROOFING $ 13,834 071950 AIR&MOISTURE BARRIERS VAPRO SHIELD/FCI CONSTRUCTORS ONLY AIR BARRIER(TYVEK)-TO EXTER WALLS N/A-EXCLUDED SF - $ 0.92 SF $ - RAIN SCREEN MOISTURE BARRIER SYSTEM- APPLIED TO EXTERIOR SHEATHING-SHEET BEHIND MASONRY&METAL MEMBRANE WALL PANELS SF 4,562.00 $ 3.22 SF $ 14,690 AIR BARRIER-TO EXTER SOFFITS N/A-EXCLUDED SF - $ 0.92 SF $ - AIR BARRIER-TO EXTER SOFFITS N/A-EXCLUDED SF - $ 0.92 SF $ - SUBTOTAL-AIR&MOISTURE BARRIERS $ 14,690 072110 BUILDING INSULATION FCI CONSTRUCTORS R30 BATTS TO U/S FLOOR DECK- ENCAPSULATED-CRAWL SPACE N/A-EXCLUDED SF - $ 2.37 SF $ - 4"/R11 FF INSULATION TO EXTERIOR WALLS WITHIN STUD CAVITIES SF 4,562.00 $ 1.09 SF $ 4,969 2.5"/R14 RIGID INSULATION-MASONRY CAVITY WALLS N/A-EXCLUDED SF - $ 3.25 SF $ - EXTER METAL STUD FRAMED 2.5"/R10.4 SEMI-RIGID INSULATION WALLS SF 4,562.00 $ 3.78 SF $ 17,244 2.5"/R10.4 SEMI-RIGID INSULATION PARAPET ASSEMBLIES SF 888.00 $ 3.78 SF $ 3,357 3.5"UN-FACED SOUND BATT INSUL INTERIOR SOUND INSUL SF 6,744.00 $ 0.86 SF 8 5,770 MISC SPRAY FOAM INSUL-CLOSED CELL BLIND APPLICATIONS LS 1.00 $ 1,900.00 LS $ 1,900 SUBTOTAL-BUILDING INSULATION $ 33,240 072700 FIRESTOPPING FCI CONSTRUCTORS FIRE STOPPING-RATED WALLS 1-HR&2-HOUR WALL ASSEMBLY LF 136.00 $ 59.52 LF 8 8,095 SUBTOTAL-FIRESTOPPING $ 8,095 074599 RAIN-SCREEN WALL ASSEMBLY KNIGHT WALL SYSTEMS/FCI CONSTRUCTORS ONLY RESYSTA HORIZONTAL PANELS-12"W COMPOSITE PANELS SF 872.00 $ - SF $ 22,741 PANEL SUPPORT GRID SYSTEM-W WALL STAND-OFF CONNECTIONS SF 1,400.00 $ - SF INCLUDED VERTICAL RIBBED PANELS-24 GA GALVALUME W/KYNAR PAINT FINISH PANEL 7.2-EXPOSED FASTENERS SF 528.00 $ 4.00 SF $ 2,112 INSTALL GRID SYSTEM HRS 100.00 $ - HRS $ 6,600 INSTALL RESYSTA PANELING HRS 80.00 $ - HRS $ 5,280 INSTALL METAL WALL PANELS HRS 32.00 $ - HRS $ 2,112 PER DIEM/TEMP HOUSING LS 1.00 $ - LS $ 3,000 SCAFFOLDING/EQUIPMENT LS 1.00 $ - LS $ 2,000 SUBTOTAL-RAIN-SCREEN WALL ASSEMBLY $ 43,845 7000 THERM&MOIS PROT FCI Constructors,Inc.Confidential Page 19 FCI Cost Worksheet 7/24/2014 I UPDATED 7/3 Project EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 070000 THERMAL&MOISTURE PROTECTION 075010 MEMBRANE ROOFING THE ROOFING COMPANY LOW SLOPE ROOFING"'*"' ADMIN WING SF 6,158.00 TPO ROOF MEMBRANE-60 MIL TH SF 6,158.00 $ 1.88 SF $ 68,973 ROOF INSULATION-R 20(UN-TAPERED) SF 6,158.00 $ 3.13 SF INCLUDED ADD FOR FULL TAPERED INSULATION ALLOWANCE LS 1.00 $ 10,000.00 LS $ 10,000 ADD FOR TAPERED INSULATION-CRICKETS SF 1224.00 $ 3.96 SF INCLUDED VAPOR BARRIER N/A-EXCLUDED SF - $ 0.22 SF $ - ROOF COVER BOARD-1/2"TH SF 6,158.00 $ 1.25 SF INCLUDED MATERAL SF 1,452.00 $ 2.92 SF INCLUDED MISC FLASHING-MEMBRANE-ROOF OPENINGS SF 100.00 $ 2.92 SF INCLUDED ROOF WALKWAY PADS SF 666.00 $ 4.40 SF INCLUDED FLASH ROOF DRAINS/OVERFLOW DRAINS EA 12.00 $ 73.00 EA INCLUDED OVERFLOW SCUPPERS EA 1.00 $ 161.00 EA INCLUDED PERIMETER COPING-PAINTED STEEL-BREAK METAL LF 299.00 $ 18.00 LF INCLUDED PAINTED METAL GUTTER N/A LF - $ 16,00 LF $ - PAINTED METAL DOWNSPOUT N/A LF - $ 16.00 LF $ - SUBTOTAL-MEMBRANE ROOFING $ 78,973 076140 SHEET METAL FLASHING FCI CONSTRUCTORS THRU-WALL FLASHING-BOW-INSTALLED BY MASON PREFINISHED-W/DRIP EDGE LF 228.00 $ 11.00 LF $ 2,608 SILL FLASHING-EXPOSED PREFINISHED-W/DRIP EDGE LF 62.00 $ 13.86 LF $ 869 SUBTOTAL-SHEET METAL FLASHING $ 3,367 077100 ROOF TIE-OFF SYSTEM ROOF TIE-OFF SYS-SS CABLES&POSTS N/A-EXCLUDED LF - $ 101.64 LF $ • SUBTOTAL-TIE-OFF SYSTEM $ - 077200 ROOF ACCESSORIES NEW ROOF HATCH-2'6"X 2'6" N/A-EXCLUDED EA - $ 2,465.00 EA $ - SMOKE VENTS N/A-EXCLUDED EA - $ 3,151.36 EA $ - SUBTOTAL-ROOF ACCESSORIES $ - 078010 APPLIED FIREPROOFING SPRAY-APPLIED FIREPROOFING N/A-EXCLUDED SF - $ 2.30 SF $ - INTUMESCENT PAINT-ON FIREPROOFING N/A-EXCLUDED SF - $ 7.70 SF $ - SUBTOTAL-APPLIED FIREPROOFING $ - 078210 UNIT SKYLIGHTS UNIT SKYLIGHTS-PREFABRICATED INSULATED UNIT W/CURB-30"X 30" N/A-EXCLUDED EA - $ 1,514.00 EA $ - SUBTOTAL-UNIT SKYLIGHTS $ . 079010 CAULKING&SEALANTS SUMMIT SEALANTS CAULKING SF 26,050.00 $ 0.65 SF $ 16,985 SUBTOTAL-CAULKING&SEALANTS $ 16,986 7000 THERM&MOIS PROT FCI Constructors,Inc.Confidential Page 20 FCI Cost Worksheet 7124/2014/UPDATED 713 Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 070000 THERMAL&MOISTURE PROTECTION-TOTALS $ 226,434 COST PER SF $ 6.69 7000 THERM&MOIS PROT FCI Constructors,Inc.Confidential Page 21 FCI Cost Worksheet 7124120141 UPDATED Ili Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 080000 DOORS&WINDOWS EVERGREEN CONSTRUCTION 081140 METAL DOORS&FRAMES SPECIALTIES HM DOORS&FRAMES-FURNISH&DELIVER LS 1.00 $ 20,172.00 LS $ 20,172 HM DOOR FRAMES-3'X 7'-16 GA-WELDED EA 13.00 $ 84.00 EA $ 1,092 HM DOOR FRAMES-3'X 7'2"-16 GA/GALVANIZED-WELDED EA 4.00 $ 90.00 EA $ 360 HM DOOR FRAMES-5'X 7'-16 GA-WELDED CORNERS EA 1.00 $ 87.00 EA $ 87 HM DOOR FRAMES-3'X 8'0"-16 GA/GALVANIZED-WELDED EA 1.00 $ 96.00 EA $ 96 HM DOOR FRAMES-4'X 8'0"-16 GA/GALVANIZED-WELDED EA 1.00 $ 105.00 EA $ 105 HM DOOR FRAMES-8'X 8'0"-16 GA/GALVANIZED-WELDED EA 2.00 $ 120.00 EA $ 240 HM DOORS-3'X 7'-16 GA/GALVANIZED-FLUSH EA 4.00 $ 240.00 EA $ 980 HM DOORS-3'X 8'-16 GA/GALVANIZED-FLUSH EA 1.00 $ 270.00 EA $ 270 HM DOORS-4'X 8'-16 GA/GALVANIZED-FLUSH EA 5.00 $ 285.00 EA $ 1,425 ADD FOR VISION PANEL CUTOUTS EA 3.00 $ - /EA $ - ADD FOR RATED DOORS EA 2.00 $ - /EA $ - LAYOUT HRS 16.00 $ 54.00 HRS $ 864 SUBTOTAL-HOLLOW METAL DOORS&FRAMES $ 25,671 EVERGREEN CONSTRUCTION 082168 SOLID CORE LAMINATE CLAD DOORS SPECIALTIES SC WOOD DOORS/HPDL FINISH-FURNISH& DELIVER LS 1.00 $ - LS INCLUDED SOLID CORE WOOD DRS-HPDL VENEER-2'6" X 7' EA 2.00 $ 240.00 /EA $ 480 7' EA 13.00 $ 240.00 /EA $ 3,120 ADD FOR VISION LIGHT KITS EA 7.00 $ - /EA $ - SUBTOTAL-SOLID CORE LAMINATE CLAD DOORS $ 3,600 083050 ACCESS DOORS FCI CONSTRUCTORS WALL/CEILING ACCESS DORS EA 4.00 $ 260.00 /EA $ 1,040 SUBTOTAL-ACCESS DOORS $ 1,040 OVERHEAD DOOR CO OF 083115 SECTIONAL OVERHEAD DOORS GRAND JUNCTION SECTIONAL OH DOOR-INSULATED/HS MOTOR OPERATED-28'0"X 20'0" INSULATED STEEL EA 1.00 $ 19,080.00 EA $ 37,467 SECTIONAL OH DOOR-INSULATED/HS MOTOR OPERATED-34'0"X 20'0" INSULATED STEEL EA 1.00 $ 22,096.00 EA INCLUDED SUBTOTAL-SECTIONAL OVERHEAD DOORS $ 37,487 OVERHEAD DOOR CO OF 083120 COILING DOORS&SHUTTERS GRAND JUNCTION COILING STEEL DOOR-1 HR RATED-12'X 9' WA-DELETED AT DD EA - $ 6,100.00 EA $ - COILING FIRE SHUTTER-3'6"X 4'2" TRAINING EA 1.00 $ 2,896.00 EA INCLUDED SUBTOTAL-COILING DOORS&SHUTTERS $ - 8000 DOORS&WINDOWS FCI Constructors,Inc.Confidential Page 22 FCI Cost Worksheet 7/24/20141 UPDATED 7/; Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL II 8000 DOORS&WINDOWS FCI Constructors,Inc.Confidential Page 23 FCI Cost Worksheet 7/24120141 UPDATED 7/; Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 080000 DOORS&WINDOWS ARCHITECTURAL WINDOW& 084105 ALUMINUM ENTRANCES&STOREFRONT DOORS EXTERIOR ALUMINUM/GLASS STOREFRONT SYSTEM-MFG STD EXTRUSIONS-ANODIZED FIN. SF 133.44 $ 41.83 SF $ 37,800 ALUMINUM FRAMED/GLAZED CURTAINWALL- ANODIZED FINISH!1"INSUL GLASS 6'MULLION FRAMES SF 560.00 $ 73.25 SF INCLUDED EXTERIOR ALUM/GLASS ENTRY DOORS-3'X 7'-MED STILE EA 2.00 $ 1,465.50 /EA INCLUDED DEFLECTION COMPENSATION HEAD CHANNELS N/A-EXCLUDED LF - $ - LF $ - ALUM STOREFRONT DOOR HARDWARE EA 2.00 $ 1,600.00 EA INCLUDED TEMP WEATHER ENCLOSURES-RHINOCLOTH SF 693.44 $ 0.94 SF $ 652 SUBTOTAL- ALUM ENTRANCES&STOREFRONTS $ 38,452 ARCHITECTURAL WINDOW& 085110 ALUMINUM WINDOWS DOORS ALUMINUM PASS-THRU WINDOWS MECHANIC'S OFFICE EA 1.00 $ 977.00 /EA INCLUDED SUBTOTAL-ALUMINUM WINDOWS $ - EVERGREEN CONSTRUCTION 087150 FINISH HARDWARE SPECIALTIES DOOR HARDWARE-HM/WOOD DOOR OPENINGS(LABOR W/DOOR INSTALLATION) EA 25.00 $ 550.00 EA INCLUDED ADD FOR PANIC/EXIT HARDWARE EA 3.00 $ 600.00 EA INCLUDED ADD FOR ELECTRONIC HARDWARE W/SECURITY SYSTEM EA - $ 1,400.00 EA $ - SUBTOTAL-FINISH HARDWARE $ . ARCHITECTURAL WINDOW& 088010 GLASS&GLAZING DOORS GLAZE HM/HPDL DOORS EA 11.00 $ 107.84 EA INCLUDED SUBTOTAL-GLASS&GLAZING $ . ARCHITECTURAL WINDOW& 088115 TRANSLUCENT GLAZED WALL SYSTEM DOORS TRANSLUCENT GLAZED WALL ASSEMBLY KALWALL OR EQUAL SF 592.00 $ 51.83 SF $ 33,220 TEMP WEATHER ENCLOSURES-RHINOCLOTH SF 592.00 $ 0.94 SF $ 556 SUBTOTAL- TRANSLUCENT GLAZED WALL SYSTEM $ 33,776 089900 ALUMINUM CURTAINWALL SYSTEM ALUMINUM FRAMED/GLAZED CURTAINWALL- LOW RISE CW SYSTEM-6° ANODIZED FINISH/1"INSUL GLASS MULLION FRAMES SF - $ 73.25 SF $ - TEMP WINDOW ENCLOSURES-RHINO CLOTH SF - $ 0.89 SF $ - EXTERIOR ALUM/GLASS ENTRY DOORS-3'X 7'-MED STILE EA - $ 1,465.50 /EA $ - SUBTOTAL-ALUMINUM CURTAINWALL SYSTEM $ 080000 DOORS&WINDOWS-TOTALS $ 140,026 COST PER SF $ 5.38 8000 DOORS&WINDOWS FCI Constructors,Inc.Confidential Page 24 • FCI Cost Worksheet 7/24/2014/UPDATED 7/; Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 080000 DOORS&WINDOWS BID ALTERNATE#4 084105 ALUMINUM ENTRANCES&STOREFRONT EXTERIOR ALUMINUM/GLASS STOREFRONT SYSTEM-MFG STD EXTRUSIONS-ANODIZED FIN. SF (560.00) $ 31.00 SF $ (1,400) SUBTOTAL- ALUM ENTRANCES&STOREFRONTS $ (1,400) 8000 DOORS&WINDOWS FCI Constructors,Inc.Confidential Page 25 FCI Cost Worksheet 7/24/2014 I UPDATED 7/3' Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,060 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 090000 FINISHES 092510 DRYWALL&METAL SUPPORT FRAMING PEAK INTERIORS EXTERIOR WALLS""""'"'""""'""""'"""' EXTERIOR WALLS-4"STUDS"'"""`""" LOAD-BEARING ASSEMBLY SF 4,562.00 4"METAL TRACK-T&8-18 GA LF 848.00 $ 6.70 LF $ 249,493 4"METAL STUD FRAMING-16 GA/16"OC LF 3,024.00 $ 4.60 LF INCLUDED 6"METAL TRACK-T&0-14 GA LF 322.00 $ 8.40 LF INCLUDED 6"METAL STUD FRAMING-16 GA/16"OC LF 2,336.00 $ 6.49 LF INCLUDED BOX HEADER ASSEMBLIES LF 80.00 $ 10.50 LF INCLUDED ADDITIONAL SUPPORT©SILLS LF 32.00 $ 7.50 LF INCLUDED BEADS/TRIM LF 15.00 $ 2.95 LF INCLUDED 22 GAGE SHEAR WALL SHEATHING SF - $ 2.75 SF $ 4,000 1 1/2"INSULATION TO EXTERIOR WALLS W/072110 SF - $ 2.75 SF $ - EXTERIOR GYPSUM SHEATHING- DENSEGLASS OR EQUAL SF 4,562.00 $ 1.95 SF INCLUDED EXTERIOR GYPSUM SHEATHING- DENSEGLASS OR EQUAL BACK SIDE OF PARAPETS SF 644.00 $ 1.95 SF INCLUDED SIDE SF 3,648.00 $ 1.19 SF INCLUDED RI9 BATT INSULATION TO EXTERIOR WALLS W/072110 SF - $ 0.85 SF WANSULATION TAPE&FINISH DW SF 3,648.00 $ 0.84 SF INCLUDED INTERIOR PARTITIONS"""`"""" DRYWALL PTN-LOAD BEARING WALLS-14' FULL HEIGHT WALLS-1 LAYER H EACH SIDE-W/SAB INSULATION LF 107.00 4"MTL TRACK-T&B-18 GAGE LF 214.00 $ 5.65 LF INCLUDED 4"MTL STUD FRAMING-16 GAGE LF 1,498.00 $ 5.00 LF INCLUDED BEADS/TRIM LF 107.00 $ 2.95 LF INCLUDED 5/8"DW TO STUDS SF 2,996.00 $ 1.04 SF INCLUDED ACOUSTIC INSULATION TO WALLS W/072110 SF - $ 0.86 SF $ - TAPE&FINISH DW TO CEILING HT SF 2,140.00 $ 0.70 SF INCLUDED DRYWALL PTN-LOAD BEARING WALLS-14' FULL HEIGHT WALLS-1 LAYER H EACH SIDE-W/SAB INSULATION LF 25.00 6"MTL TRACK-T&B-14 GAGE LF 50.00 $ 8.25 LF INCLUDED 6"MTL STUD FRAMING-16 GAGE LF 350.00 $ 7.00 LF INCLUDED BEADS/TRIM LF 25.00 $ 2.95 LF INCLUDED 5/8"DW TO STUDS SF 700.00 $ 1.04 SF INCLUDED ACOUSTIC INSULATION TO WALLS W/072110 SF - $ 0.86 SF $ - TAPE&FINISH DW TO CEILING HT SF 500.00 $ 0.70 SF INCLUDED FULL HEIGHT WALLS-1 LAYER DRYWALL PTN-DEMSING WALLS-14'H EACH SIDE-W/SAB INSULATION LF 304.00 4"MTL TRACK-T&B LF 608.00 $ 5.43 LF INCLUDED ADD FOR SLIP/DEFLECTION TRACK LF 304.00 $ 2.90 LF INCLUDED 4"MTL STUD FRAMING LF 4,256.00 $ 3.76 LF INCLUDED BEADS/TRIM LF 304.00 $ 2.95 LF INCLUDED 5/8"DW TO STUDS SF 8,512.00 $ 1.04 SF INCLUDED ACOUSTIC INSULATION TO WALLS W/072110 SF - $ 0.86 SF $ - TAPE&FINISH DW TO CEILING HT SF 6,080.00 $ 0.70 SF INCLUDED FULL HEIGHT WALLS-1 LAYER DRYWALL PTN-DEMSING WALLS-14'H EACH SIDE-W/SAB INSULATION LF 31.00 6"MTL TRACK-T&B LF 62.00 $ 6.10 LF INCLUDED ADD FOR SLIP/DEFLECTION TRACK LF 31.00 $ 3.32 LF INCLUDED 6"MTL STUD FRAMING LF 434.00 $ 4.65 LF INCLUDED BEADS/TRIM LF 31.00 $ 2.95 LF INCLUDED 518"DW TO STUDS SF 868.00 $ 1.04 SF INCLUDED ACOUSTIC INSULATION TO WALLS W/072110 SF - $ 0.86 SF $ - TAPE&FINISH DW TO CEILING HT SF 620.00 $ 0.70 SF INCLUDED DRYWALL PTN-FURRING OF CMU WALLS- FULL HEIGHT WALLS-1 LAYER 1 14'H SIDE-W/SAB INSULATION LF 95.00 4"MTL TRACK-T&B LF 190.00 $ 5.43 LF INCLUDED ADD FOR SLIP/DEFLECTION TRACK LF 95.00 $ 2.90 LF INCLUDED 4"MTL STUD FRAMING LF 1,330.00 $ 3.76 LF INCLUDED BEADS/TRIM LF 95.00 $ 2.95 LF INCLUDED 5/8"DW TO STUDS SF 1,330.00 $ 1.04 SF INCLUDED 9000 FINISHES FCI Constructors,Inc.Confidential Page 26 FCI Cost Worksheet 712412014/UPDATED 713• Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL ACOUSTIC INSULATION TO WALLS W/072110 SF - $ 0.86 SF $ - TAPE&FINISH DW TO CEILING HT SF 950.00 $ 0.70 SF INCLUDED 090000 FINISHES 092510 DRYWALL&METAL SUPPORT FRAMING FULL HEIGHT WALLS-1 LAYER DRYWALL PM-CHASE WALLS-14'H EACH SIDE-W/SAB INSULATION LF 11.00 4"MTL TRACK-T&B LF 22.00 $ 5.43 LF INCLUDED ADD FOR SLIP/DEFLECTION TRACK LF 11.00 $ 2.90 LF INCLUDED 4"MTL STUD FRAMING LF 154.00 $ 3.76 LF INCLUDED BEADS/TRIM LF 11.00 $ 2.95 LF INCLUDED 5/8"DW TO STUDS SF 154.00 $ 1.04 SF INCLUDED ACOUSTIC INSULATION TO WALLS W/072110 SF - $ 0.86 SF $ - TAPE&FINISH DW TO CEILING HT SF 110.00 $ 0.70 SF INCLUDED DRYWALL CEILINGS-SINGLE LAYER W/ BLACK IRON SUPPORT`""""'*' INTERIOR GYP BD CEILINGS 1 1/2"MAIN CARRIER CHANNELS LF 239.25 $ 4.48 LF INCLUDED 7/8"CROSS RUNNERS LF 362.50 $ 3.40 LF INCLUDED 5/8"DW TO CEILINGS SF 725.00 $ 1.62 SF INCLUDED TAPE&FINISH DW CEILINGS SF 725.00 $ 0.59 SF INCLUDED CF FRAMED HEADERS LF 88.00 $ 10.60 LF INCLUDED DRYWALL CEILINGS-SINGLE LAYER FURRED TO U/S ROOF STRUCTURE********* INTERIOR GYP BD CEILINGS 7/8"HAT CHANNELS LF 212.50 $ 3.40 LF INCLUDED 5/8"DW TO CEILINGS SF 425.00 $ 1.62 SF INCLUDED TAPE&FINISH DW CEILINGS SF 425.00 $ 0.59 SF INCLUDED DRYWALL DUCT ENCLOSURE-RATED**"""" SF $ - SF 4"MTL TRACK N/A-EXCLUDED LF - $ 6.36 LF $ - 4"MTL STUD FRAMING N/A-EXCLUDED LF - $ 4.40 LF $ - CORNER BEADS N/A-EXCLUDED LF - $ 2.67 LF $ - 5/8"DW TO FASCIAS/SOFFITS N/A-EXCLUDED SF - $ 1.50 SF $ - TAPE&FINISH DW FASCIAS/SOFFITS N/A-EXCLUDED SF - $ 0.90 SF $ - MISCELLANEOUS DRYWALL/INTERIORS ITEMS. * DRYWALL COLUMN COVERS-INTERIOR N/A-EXCLUDED EA - $ 268.00 EA $ - SKYLIGHT WELLS N/A-EXCLUDED LF - $ 49.00 LF $ • CEILING BULKHEADS LF 6.00 $ 38.60 LF INCLUDED ADD FOR LEVEL 5 FINISH ON EXPOSED SURFACES N/A-EXCLUDED SF - $ 1.03 SF $ - ADD FOR TILE BACKER BOARD AT TOILET ROOMS SF 790.00 $ 1.00 SF INCLUDED ADD FOR MOLD RESISTANT GYP BOARD SF 1,284.00 $ 0.65 SF INCLUDED FRP WALL PANELS-60"H WAINSCOT JANITORS'CLOSETS LS 1.00 $ 1,500.00 LS $ 1,500 ACOUSTICAL SEALANTS/TRIM CLOSURES LS 1.00 $ - LS $ 9,800 SHOP DWGS FOR COLD FORMED METAL FRAMING EXCLUDED LS 1.00 $ - LS $ - TEMPORARY HEAT FOR INTERIORS MO 2.00 $ 12,500.00 MO $ 25,000 LAYOUT/COORDINATION-INTERIORS HRS 80.00 $ 54.00 HRS $ 4,320 CLEANUP/FINAL CLEANING HRS 100.00 $ 39.00 HRS $ 3,900 DUMPSTERS PULLS 3.00 $ 1,000.00 PULL$ 3,000 SUBTOTAL-DRYWALL&METAL SUPPORT FRAMING $ 301,013 093150 CERAMIC TILE PORC CERAMIC FLOOR TILE-THIN SET TOILET ROOMS SF 388.00 $ 15.00 SF $ 23,300 PORC CERAMIC TILE BASE-COVED- ADHESIVE SET TOILET ROOMS LF 158,00 $ 16.23 LF INCLUDED PORCELAIN CERAMIC WALL TILE-ADHESIVE SET-60"WAINSCOT TOILET ROOMS SF 790.00 $ 14.50 SF INCLUDED ADD FOR EPDXY MORTAR&GROUT N/A-EXCLUDED SF - $ 4.33 SF $ - ADD FOR ANTI-FRACTURE MEMBRANE TOILET ROOMS SF 388.00 $ 4.40 SF INCLUDED 9000 FINISHES FCI Constructors,Inc.Confidential Page 27 FCI Cost Worksheet 7/2412014/UPDATED 7/3• Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL SUBTOTAL-CERAMIC TILE $ 23,300 095110 ACOUSTICAL CEILINGS PEAK INTERIORS ACT CEILINGS-2'X 2'-EXPOSED TEE GRID- DIRECT HUNG FROM STRUCT. TEGULAR EDGE TILE SF 636.00 $ 4.05 SF INCLUDED ACT CEILINGS-2'X 4'-EXPOSED TEE GRID- DIRECT HUNG FROM STRUCT. TEGULAR EDGE TILE SF 1,890.00 S 3.90 SF INCLUDED 1 RECESSED SHADE POCKET PAINTED STEEL LF 65.00 $ 22.00 LF $ 1,430 SUBTOTAL-ACOUSTICAL CEILINGS $ 1,430 090000 FINISHES 096600 ACOUSTICAL TREATMENT ACOUSTICAL WALL PANELS N/A-EXCLUDED SF - $ 27.50 SF S - SUBTOTAL-ACOUSTICAL TREATMENT $ - 086510 RESILIENT FLOOR&BASE VCT FLOOR TILE SF 660.00 $ 2.58 SF $ 1,706 LINOLEUM SHEET FLOORING N/A-EXCLUDED SF - $ 6.77 SF $ - FORBO FLOOR TILE SF 146.00 $ 8.00 SF $ 1,168 4"H RUBBER BASE-COVED LF 1,094.00 $ 2.40 LF $ 2,826 FLOOR PREP-ALLOW 25% SF 201.50 $ 0.60 SF $ 121 SUBTOTAL-RESILIENT FLOORING $ 5,620 096810 CARPET GLUEDOWN SY 222.48 $ 40.00 SY $ 8,899 SUBTOTAL-CARPET $ 8,899 099000 PAINTING&WALLCOVERING WBS COATINGS PAINT DRYWALL PTNS-LATEX-SINGLE COLOR SF 7,902.00 $ 0.79 SF $ 35,288 PAINT CMU PTNS-LATEX SF 4,512.00 $ 0.96 SF INCLUDED PAINT DRYWALL CEILINGS-LATEX-SINGLE COLOR SF 1,150.00 $ 1.29 SF INCLUDED PAINT DRYWALL PTNS-EPDXY-SINGLE COLOR N/A-EXCLUDED SF - $ 1.21 SF $ - PAINT CMU PTNS-EPDXY SF - $ 1.38 SF INCLUDED PAINT EXPOSED STEEL STRUCTURE SF 2,052.00 $ 0.77 SF INCLUDED PAINT HM DOOR FRAMES EA 22.00 $ 60.80 EA INCLUDED PAINT HM DOORS EA 10.00 $ 56.50 EA INCLUDED PAINT EXPOSED COLUMNS TO 10 FTAFF EA 22.00 $ 244.00 EA INCLUDED PAINT PIPE BOLLARDS EA - $ 55.50 EA $ - PAINT EXPOSED STEEL TRANSFER BEAM LF 26.00 $ 9.13 LF INCLUDED SEALER/GRAFITTI GUARD-EXTERIOR CMU WALLS ONLY SF 2,805.00 $ 1.35 SF INCLUDED SEALER/GRAFITTI GUARD-EXPOSED EXTERIOR CONC WALLS SF 1,792.00 $ 1.35 SF INCLUDED STAIN&SEALER-COMPOSITE PLANK SIDING SF - $ 1.80 SF $ - STAIN&SEALER-WOOD BEAMS&T&G WOOD EXTER SOFFITS SF 224.00 $ 1.80 SF INCLUDED MISC TOUCHUP PAINTING HRS 48.00 $ 57.00 HRS $ 2,736 WALLCOVERING $ 38,024 099100 PAVEMENT MARKINGS LINE STRIPPING/PAVEMENT MARKINGS- INTERIOR APPARATUS BAYS N/A-EXCLUDED SF - $ 0.22 SF $ - SUBTOTAL-PAVEMENT MARKINGS $ - 9000 FINISHES FCI Constructors,Inc.Confidential Page 28 FCI Cost Worksheet 7/2412014/UPDATED 713' Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 099650 CONCRETE FLOOR SEALING WBS COATINGS CHEM RESISTANT FLOOR COATING SF - $ 0.66 SF $ - STANDARD HOUSEKEEPING FLOOR SEALER INTERIOR APPARATUS BAYS SF 22,102.00 $ 0.75 SF $ 16,242 SUBTOTAL-CONCRETE FLOOR SEALING $ 16,242 099665 CONCRETE FLOOR STAIN ACID FLOOR STAIN SF 155.00 $ 156.20 SF $ 1,882 SUBTOTAL-CONCRETE FLOOR STAIN $ 1,882 090000 FINISHES-TOTALS $ 396,410 COST PER SF $ 15.22 9000 FINISHES FCI Constructors,Inc.Confidential Page 29 FCI Cost Worksheet 7124/2014/UPDATED 713' Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 090000 FINISHES BID ALTERNATE#2 099000 PAINTING&WALLCOVERING PAINT EXPOSED STEEL STRUCTURE STORAGE PLATFORM SF 704.00 $ - SF $ 3,000 WALLCOVERING _ $ 3,000 9000 FINISHES FCI Constructors,Inc.Confidential Page 30 FCI Cost Worksheet 7/24/2014/UPDATED 713 Project: EAGLE COUNTY REGIONAL AIRPORT.SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 100000 SPECIALTIES 101000 VISUAL DISPLAY BOARDS MARKERBOARDS-10'X 4' N/A-EXCLUDED EA - $ 550.00 EA $ - TACK BOARD-4'X 4' N/A-EXCLUDED EA - $ 240.00 EA $ - SUBTOTAL-VISUAL DISPLAY BOARDS $ - 101505 TOILET PARTITIONS SIMPSON&SIMPSON TOILET PTNS-FLR MTD/OH BRACED-STEEL- BAKED ENAMEL FIN EA 1.00 $ 880.00 EA $ 7,195 TOILET PTNS-HC-FLR MTD/OH BRACED- STEEL-BAKED ENAMEL FIN EA 2.00 $ 1,060.00 EA INCLUDED URINAL SCREENS-WALL MTD-STEEL-BAKED ENAMEL FIN EA 1.00 $ 250.00 EA INCLUDED SUBTOTAL-TOILET PARTITIONS $ 7,195 102600 WALL&CORNER PROTECTION CORNER GUARDS-48"STAINLESS STEEL- SURF MOUNTED N/A-EXCLUDED EA - $ 52.00 EA $ - SUBTOTAL-WALL&CORNER PROTECTION $ - 103510 FLAGPOLES 20 FT TAPERED FLAGPOLE-EXPOSED HALYARD N/A-EXCLUDED LS LS $ - EXCAV/SET ANCHOR SLEEVE/CONCRETE/ERECTION N/A-EXCLUDED EA $ 984.00 EA $ - SUBTOTAL-FLAGPOLES $ - 104010 IDENTIFYING DEVICES(SIGNAGE) FCI CONSTRUCTORS INTERIOR ROOM SIGNS FURNISH 8 INSTALL EA 21.00 $ 74.80 EA $ 1,671 WALL MOUNTED LETTERING-NON ILLUMINATED/CAST ALUM-18"HIGH N/A-EXCLUDED EA - $ 180.00 EA $ - WALL MOUNTED LETTERING-NON ILLUMINATED/CAST ALUM-12"HIGH N/A-EXCLUDED EA - $ 160.00 EA $ - WALL MOUNTED LETTERING-NON ILLUMINATED/CAST ALUM-8"HIGH N/A-EXCLUDED EA - $ 101.00 EA $ - METAL CLAD BACKING PLATES-EXTERIOR SIGN PANELS N/A-EXCLUDED SF - $ 46.00 SF $ - BUILDING DEDICATION PLAQUE EA 1.00 $ 1,240.00 EA $ 1,240 BUILDING DIRECTORY N/A-EXCLUDED EA - $ 795.00 EA $ - SUBTOTAL-INDENTIFYING DEVICES $ 2,811 104420 METAL LOCKERS METAL LOCKERS-PAINTED STEEL STAFF LOCKERS EA 8.00 $ 255.00 EA $ 2,040 LOCKER BENCH 3'6"LONG-BUILT IN EA 1.00 $ 640.00 EA $ 640 SUBTOTAL-METAL LOCKERS $ 2,680 105205 FIRE EXTINGUISHERS&CABS FCI CONSTRUCTORS FIRE EXTINGUISHERS AS SHOWN EA 3.00 $ 85.00 EA $ 255 FIRE EXTINGUISHER MOUNTING BRACKETS AS SHOWN EA 3.00 $ 55.00 EA $ 165 FIRE EXTINGUISHER CABINETS AS SHOWN EA - $ 185.00 EA $ - FIRE EXTINGUISHERS ALLOWANCE FOR ADMIN AREA EA 2.00 $ 85.00 EA $ 170 FIRE EXTINGUISHER CABINETS ALLOWANCE FOR ADMIN AREA EA 2.00 $ 185.00 EA $ 370 10000 SPECIALTIES FCI Constructors,Inc.Confidential Page 31 FCI Cost Worksheet 7/24/2014/UPDATED 713 Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL SUBTOTAL-FIRE EXTINGUISHERS&CABINETS $ 960 10000 SPECIALTIES FCI Constructors,Inc.Confidential Page 32 FCI Cost Worksheet 7/24/2014/UPDATED 713 Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 100000 SPECIALTIES 106120 OPERABLE WALLS OPERABLE WALL ASSEMBLY-MANUAL OPERATED-VINYL FACED FABRIC N/A-EXCLUDED LF - $ 516.00 LF $ - SUBTOTAL-OPRABLE WALLS $ - 108010 TOILET ROOM ACCESSORIES SIMPSON&SINPSON TOILET PAPER HOLDER EA 4.00 $ 68.00 EA INCLUDED HANDICAP BRAG BARS EA 12.00 $ 109.00 EA INCLUDED LIQUID SOAP DIPSENSER EA 5.00 $ 70.00 EA INCLUDED SEAT COVER DISPENSER EA 4.00 $ 75.00 EA INCLUDED PAPER TOWEL DISPENSERNVAST RECEPTACLE TOILET RMS EA 3.00 $ 447.00 EA INCLUDED PAPER TOWEL DISPENSER EMPLOYEE BREAK RM EA 1.00 $ 91.00 EA INCLUDED SANITARY NAPKIN DISPENSER N/A-EXCLUDED EA - $ 225.00 EA $ - SANITARY NAPKIN DISPOSAL EA 2.00 $ 70.00 EA INCLUDED FRAMED MIRROR-24"X 36" EA 1.00 $ 195.00 EA INCLUDED FRAMED MIRROR-24"X 48" EA 1.00 $ 205.00 EA INCLUDED FRAMED MIRROR-54"X 36" EA 2.00 $ 420.00 EA INCLUDED ELECTRIC HAND DRYER N/A-EXCLUDED EA - $ 540.00 EA $ - JANITOR'S MOP RACK EA 1.00 $ 210.00 EA INCLUDED UNDERCOUNTER LAV GUARD N/A-EXCLUDED EA - $ 70.00 EA $ - SHOWER RODS EA 1.00 $ 52.00 EA INCLUDED HC GRAB BARS-SHOWERS EA 2.00 $ 95.00 EA INCLUDED TOWEL/CLOTHES HOOKS EA 8.00 $ 30.00 EA INCLUDED FOLD-DOWN SHOWER SEATS EA 1.00 $ 275.00 EA INCLUDED SUBTOTAL-TOILET ROOM ACCESSORIES $ - 109950 MISCELLANEOUS SPECIALTIES FCI CONSTRUCTORS KNOX BOX EA 1.00 $ 717.12 EA $ 717 SUBTOTAL-MISCELLANEOUS SPECIALTIES $ 717 10000 SPECIALTIES-TOTALS $ 14,363 COST PER SF $ 0.5$ 10000 SPECIALTIES FCI Constructors,Inc.Confidential Page 33 FCI Cost Worksheet 7/24/2014/UPDATED 7/3 Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 110000 EQUIPMENT 111119 MAINTENANCE EQUIPMENT VEHICLE MAINT EQUIPMENT N/A-EXCLUDED LS - $ - LS $ - SUBTOTAL-MAINTENANCE EQUIPMENT $ - 111120 WASH EQUIPMENT HOTSEY PRESSURE WASHER N/A-OWNER FF&E LS - $ 13,000.00 LS $ - MOBILE PLATFORM LIFTS N/A-OWNER FF&E LS - $ 10,000.00 LS $ - SUBTOTAL-WASH EQUIPMENT $ - 111190 FUEL DISPENSING EQUIPMENT FUEL DISPENSING EQUIPMENT N/A-EXCLUDED LS - $ - LS $ - SUBTOTAL-FUEL DISPENSING EQUIPMENT $ - 1 111310 AUDIO VISUAL EQUIPMENT PROJECTION SCREEN-CLG MTD-ELEC OPERATED-7'X 7'W N/A-EXCLUDED EA - $ 2,230.00 EA $ - FLAT SCREEN TV MONITORS-BRACKET MTD N/A-OWNER FF&E EA - $ 660.00 EA $ - FLAT SCREEN TV MONITOR MOUNTS-CLG MTD N/A-OWNER FF&E EA - $ 285.00 EA $ - AV PROJECTOR-CEILING MOUNTS N/A-OWNER FF&E EA - $ 245.00 EA $ - AV EQUIPMENT N/A-OWNER FF&E LS - $ 25,000.00 LS $ - SUBTOTAL-AUDIO VISIUAL EQUIPMENT $ - 114550 RESIDENTIAL APPLIANCES FCI CONSTRUCTORS OFCI REFRIGERATOR EA 1.00 $ 120.00 EA $ 120 OFCI DISHWASHER-UNDERCOUNTER EA 1.00 $ 180.00 EA $ 180 OFCI MICROWAVE OVEN-1 CF CAP EA 1.00 $ 60.00 EA $ 60 OFCI COFFE MAKER- EA 1.00 $ 60.00 EA $ 60 STOVE/RANGE N/A-EXCLUDED EA - $ 150.00 EA $ - DUCTLESS EXHAUST HOOD N/A-EXCLUDED EA - $ 120.00 EA $ - OFCI WASHER EA 1.00 $ 120.00 EA $ 120 OFCI CLOTHES DRYER EA 1.00 $ 120.00 EA $ 120 SUBTOTAL-RESIDENTIAL APPLIANCES $ 660 110000 EQUIPMENT-TOTALS $ 660 COST PER SF $ 0.03 11000 EQUIPMENT FCI Constructors,Inc.Confidential Page 34 FC1 Cost Worksheet 7124/2014/UPDATED 7/1 Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 120000 FURNISHINGS 124840 FLOOR MATS AND FRAMES ENTRY MATS-RECESSED PEDIMAT N/A-EXCLUDED SF - $ 29.32 SF $ - SUBTOTAL-FLOOR MATS $ - 1249110 WINDOW TREATMENTS MANUAL ROLLER SHADES SF - $ 20.75 SF $ - BLACK-OUT SHADES-MAUNAL OPER N/A-EXCLUDED SF - $ 21.00 SF $ - SUBTOTAL-WINDOW TREATMENTS $ - 120000 FURNISHINGS-TOTALS $ - COST PER SF $ - BID ALTERNATE#3 1249110 WINDOW TREATMENTS AMABASSADOR BUNDS&SHUTTER TRAINING ROOM&OPEN OFFICE MANUAL ROLLER SHADES ONLY SF 372.00 $ 20.75 SF $ 3,766 SUBTOTAL-WINDOW TREATMENTS $ 3,766 $ 0.14 SF 120000 FURNISHINGS-TOTALS $ 3,766 12000 FURNISHINGS FCI Constructors,Inc.Confidential Page 35 FCI Cost Worksheet 7/24/2014/UPDATED 7r Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 130000 SPECIAL CONSTRUCTION 132710 PRE-ENGINEERED METAL BUILDINGS PRE-ENGINEERED METAL BUILDING-FURNISH&DELIVER METAL BUILDING-MAIN FRAMES,COLUMNS, END WALLS-PRIME PTD-FURNISH HIGH BAY APPARATUS BAYS SF 20,194.00 $ 11.00 SF $ 837,137 ROOF PURLINS-12"DEEP-36"OC HIGH BAY APPARATUS BAYS LF 8,021.20 $ 2.85 LF INCLUDED BRACING STRUTS EVERY3RDPURLIN EA 192.72 $ 5.00 EA INCLUDED CABLE BRACES HIGH BAY APPARATUS BAYS EA 8.00 $ 450.00 EA INCLUDED EXTERIOR WALL FRAMING-CF PURLINS PRIME PTD-6"DEEP-48"OC BI-PASS GIRTS LF 3,864.58 $ 2.10 LF INCLUDED EXTERIOR SOFFIT FRAMING-CF PURLINS PRIME PTD LF 388.30 $ 4.00 LF INCLUDED ROOF TOP EQUIPMENT CURBS LS 1.00 $ 3,500.00 LS $ 9,500 EXTERIOR WALL PANELS-CONCEALED FASTENERS-FACTORY PAINT FIN-24 GA SF 14,053.00 $ 2.00 SF INCLUDED INTERIOR LINER WALL PANELS-CONCEALED FASTENERS-FACTORY PAINT FIN-26 GA TO 14'AFF SF 5,264.00 $ 1.65 SF INCLUDED STANDING SEAM ROOF PANELS-22 GA PTD STEEL-FACTORY FIN-MAIN ROOF HIGH BAY APPARATUS BAYS SF 21,333.00 $ 4.65 SF INCLUDED INTERIOR LINER CEILING PANELS-EXPOSE FASTENERS-FACTORY PAINT FIN-26 GA N/A-EXCLUDED SF - $ 1.40 SF $ - EXTERIOR PERIMETER FASCIA TRIM 24GA PREFORMED/PAINTED LF 672.10 $ 3.50 LF INCLUDED EXTERIOR PERIMETER SOFFIT PANELS 24 GA PREFORMED/PAINTED SF 646.80 $ 3.50 SF INCLUDED SNOW GUARDS-2 LINE PTD STEEL AS SHOWN LF 501.00 $ 16.00 LF INCLUDED SNOW GUARDS-2 LINE PTD STEEL ADD FOR ADD'L NEEDED LF 501.00 $ 16.00 LF INCLUDED PERIMETER GUTTERS&DOWNSPOUTS N/A-EXCLUDED LF - $ - LF $ - EXIT DOOR CANOPY STRUCTURE EA 3.00 $ 1,120.00 EA INCLUDED THERMAL BLOCK INSULATION-ROOF PURLINS FURNISH LF 8,021.20 $ 3.00 LF INCLUDED THERMAL BLOCK INSULATION-WALL GIRTS FURNISH LF 3,864.58 $ 3.00 LF INCLUDED SUBTOTAL•MATERIALS FURNISHED&DEUVERED $ 840,637 PRE-ENGINEERED METAL BUILDING-ERECTION W/INSTALL OF INSULATION METAL BUILDING ERCTION-STRUCTURE MAIN FRAMES/END WALLS DY 18.00 $ 5,650.00 DY INCLUDED INSTALL ROOF PURLINS HIGH BAY APPARATUS BAYS LF 8,021.20 $ 2.34 LF INCLUDED INSTALL WALL GIRTS HIGH BAY APPARATUS BAYS LF 3,864.58 $ 2.08 LF INCLUDED INSTALL WALL PANELS HIGH BAY APPARATUS BAYS SF 14,053.00 $ 1.17 SF INCLUDED INSTALL WALL LINER PANELS HIGH BAY APPARATUS BAYS SF 5,264.00 $ 1.17 SF INCLUDED INSTALL ROOF PANELS HIGH BAY APPARATUS BAYS SF 21,333.00 $ 1.50 SF INCLUDED INSTALL CEILING LINER PANELS N/A-EXCLUDED SF - $ 2.34 SF $ - INSTALL EXTERIOR PERIMETER FASCIA TRIM 24GA PREFORMED/PAINTED LF 672.10 $ 3.13 LF INCLUDED INSTALL EXTERIOR PERIMETER SOFFIT PANELS 24 GA PREFORMED/PAINTED SF 646.80 $ 3.13 SF INCLUDED INSTALL SNOW GUARDS-2 LINE PTD STEEL AS SHOWN LF 501.00 $ 7.50 LF INCLUDED INSTALL SNOW GUARDS-2 LINE PTD STEEL ADD FOR ADD'L NEEDED LF 501.00 $ 7.50 LF INCLUDED EXIT DOOR CANOPY STRUCTURE EA 3.00 $ 1,200.00 EA INCLUDED EXTERIOR WALL INSULATION-R13 BATTS VINYL FABRIC FACED-2 LAYERS INSTALL SF 28,106.00 $ 0.59 SF INCLUDED ROOF INSULATION-R19 BATTS VINYL FABRIC FACED INSTALL SF 21,333.00 $ 1.17 SF INCLUDED ROOF INSULATION-R13 BATTS VINYL FABRIC FACED INSTALL SF 21,333.00 $ 0.90 SF INCLUDED THERMAL BLOCK INSULATION-ROOF PURUNS INSTALL LF 8,021.20 $ 1.00 LF INCLUDED THERMAL BLOCK INSULATION-WALL GIRTS INSTALL LF 3,864.58 $ 1.00 LF INCLUDED SMALL TOOLS&SAFETY LS 1.00 $ 2,200.00 LS INCLUDED MANLIFTS LS 1.00 $ 8,000.00 LS INCLUDED 130000 SPECIAL CONSTR FCI Constructors,Inc.Confidential Page 36 FCI Cost Worksheet 7/24/2014/UPDATED 7/: Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL SUBTOTAL-METAL BUILDING ERECTION $ - 130000 SPECIAL CONSTRUCTION 132710 PRE-ENGINEERED METAL BUILDINGS PRE-ENGINEERED METAL BUILDING INSULATION-FURNISH&DELIVER EXTERIOR WALL INSULATION-R13 BATTS VINYL FABRIC FACED FURN&DEL SF 28,106.00 $ 0.45 SF INCLUDED ROOF INSULATION-R19 BATTS VINYL FABRIC FACED FURN&DEL SF 21,333.00 $ 1.10 SF INCLUDED ROOF INSULATION-R13 BATTS VINYL FABRIC FACED FURN&DEL SF 21,333.00 $ 0.35 SF INCLUDED MISC THERMAL BREAK INSULATION LS 1.00 $ 1,500.00 LS INCLUDED SUBTOTAL-METAL BUILDING INSULATION-FURNISH $ - LAYOUT/COORDINATION-BLDG STRUCTURE& ENCLOSURE HR 200.00 $ 54.00 HR $ 10,800 CLEANUP LABOR-BLDG STRUCTURE& ENCLOSURE HR 200.00 $ 38.56 HR $ 7,712 DUMPSTERS EA 5.00 $ 1,000.00 EA $ 5,000 POST AWARD SCOPE CHANGES LS 1.00 $ 15,000.00 LS $ 15,000 ACCEPTANCE OF PEMB BID PKG BID ALTERNATE 3A LS (1.00) $ 34,813.00 LS $ (34,813) SUBTOTAL-PRE ENGINEERED METAL BUILDINGS $ 3,699 130000 SPECIAL CONSTRUCTION-TOTALS $ 844,336 COST PER SF $ 32.41 130000 SPECIAL CONSTR FCI Constructors,Inc.Confidential Page 37 FCI Cost Worksheet 7124120141 UPDATED 713 Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 210000 FIRE SUPPRESSION SYSTEMS 215300 FIRE PROTECTION WORK CURTIS ENGINEERING FIRE SPRINKLERS-WET PIPE SYSTEM+ STANDPIPES ADMINISTRATION AREA SF 5,611.00 $ 2.85 SF $ 68,900 FIRE SPRINKLERS-WET PIPE SYSTEM+ STANDPIPES INTERIOR APPARATUS BAYS SF 20,439.00 $ 2.90 SF INCLUDED FIRE SPRINKLERS-ADD FOR DRY TYPE SYSTEM SF 22,094.00 $ 1.00 SF INCLUDED FIRE SPRINKLERS-FREEZE PROOF SYSTEM- EXTERIOR BUILDING OVERHANG SOFFITS SF - $ - SF INCLUDED BOOSTER PUMP N/A-EXCLUDED LS - $ - LS $ - JOCKEY PUMP N/A-EXCLUDED LS - $ - LS $ - SUBTOTAL-FIRE PROTECTION WORK $ 68,900 $ 2.64 SF 210000 FIRE SUPPRESSION-TOTALS $ 68,900 COST PER SF $ 2.64 BID ALTERNATE#5 215300 FIRE PROTECTION WORK CUR71S ENGINEERING FIRE SPRINKLERS-ADD FOR DRY TYPE SYSTEM SF (22,094.00) $ 0.50 SF $ (9,300) SUBTOTAL-FIRE PROTECTION WORK $ (9,300) $ (0.36)SF 210000 FIRE SUPPRESSION-TOTALS $ (9,300) BID ALTERNATE#6 215300 FIRE PROTECTION WORK CURTIS ENGINEERING FIRE SPRINKLERS-ADD FOR DRY TYPE SYSTEM ADD NITROGEN GENERATOR LS 1.00 $ 14,900.00 LS $ 14,900 SUBTOTAL-FIRE PROTECTION WORK $ 14,900 $ 0.67 SF 210000 FIRE SUPPRESSION-TOTALS $ 14,900 210000 FIRE SUPPRESSION FCI Constructors,Inc.Confidential Page 38 FCI Cost Worksheet 7/24/2014/UPDATED 7/3 Project: EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 22/230000 MECHANICAL 220000 PLUMBING ADMINISTRATION WING SF 5,611.00 $ - SF $ 218,723 STORAGE/WORK APPARATUS BAYS SF 20,439.00 $ - SF INCLUDED PLUMBING EQUIPMENT LS 26,050.00 $ - LS INCLUDED DOMESTIC WATER PIPING LS 26,050.00 $ - LS INCLUDED SANITARY SERVICE PIPING LS 26,050.00 $ - LS INCLUDED VENT PIPING SF 26,050.00 $ - SF INCLUDED WASH EQUIPMENT-ROUGH IN&SERVICES SF 26,050.00 $ - SF INCLUDED MAINT EQUIPMENT-ROUGH IN&SERVICES SF 26,050.00 $ - SF INCLUDED NAT GAS PIPING/RADIANT HEATERS SF 26,050.00 $ - SF INCLUDED PLUMBING FIXTURES-W/TRIM SF 26,050.00 $ - SF INCLUDED PLUMBING-SAND/OIL SEPERATOR SF 26,050.00 $ - SF INCLUDED PLUMBING-PREFAB TRENCH DRAINS FURNISH LF 64.00 $ 60.00 LF INCLUDED PLUMBING-PREFAB TRENCH DRAINS INSTALL LF 64.00 $ 21.00 LF INCLUDED PLUMBING PIPING INSULATION SF 26,050.00 $ - SF INCLUDED RADON GAS VENTING SYSTEM ALLOW-NOTHING SHOWN LS 1.00 $ 7,500.00 LS INCLUDED 1.5"WATER METER INSIDE MECH ROOM LS 1.00 $ 8,500.00 LS $ 8,500 LAYOUT/COORDINATION-PLUMBING WORK HRS 100.00 $ 54.00 HRS $ 5,400 TEST/FLUSH SANITIZE SYSTEMS LS 1.00 $ - LS INCLUDED SEISMIC BRACING ALLOWANCE LS 1.00 $ 3,000.00 LS $ 3,000 SUBTOTAL-PLUMBING $ 235,623 $ 9.05 SF 230000 HVAC ADMINISTRATION WING SF 5,611.00 $ 22.50 SF $ 405,540 STORAGE/WORK APPARATUS BAYS SF 20,439.00 $ 15.20 SF INCLUDED HVAC EQUIPMENT SF 26,050.00 $ - SF INCLUDED SHEET METAL-DUCTWORK SF 26,050.00 $ - SF INCLUDED GRILLES/REGISTERS/DIFFUSERS SF 26,050.00 $ - SF INCLUDED HYDRONIC HVAC PIPING SF 26,050.00 $ - SF INCLUDED HVAC SYS-VEHICLE EXHAUST/CO2 MONITORS SF 26,050.00 $ - SF INCLUDED IN-FLOOR RADIANT HEAT N/A-EXCLUDED SF - $ - SF INCLUDED SNOW MELT SYSTEM EXTERIOR 8'CONC APRONS SF 1,700.00 $ 12.00 SF INCLUDED SNOW MELT SYSTEM CONCRETE WALKS SF 325.00 $ 12.00 SF INCLUDED HVAC INSULATION SF 26,050.00 $ - SF INCLUDED HVAC CONTROLS SF 26,050.00 $ - SF INCLUDED TEST&BALANCE SF 26,050.00 $ - SF INCLUDED LAYOUT/COORDINATION-...HVAC WORK FIRS 173.00 $ 54.00 HRS $ 9,342 COMMISSIONING SF 26,050.00 $ - SF INCLUDED SEISMIC BRACING ALLOWANCE LS 1.00 $ 4,000.00 LS $ 4,000 SUBTOTAL-HVAC $ 418,882 $ 16.08 SF 221230000 MECHANICAL-TOTALS $ 654,505 COST PER SF $ 25.12 22 23 PLUMBING&HVAC FCI Constructors,Inc.Confidential Page 39 FCI Cost Worksheet 7/24/2014 t UPDATED 7/3 Project EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 22/230000 MECHANICAL BID ALTERNATE#1 220000 PLUMBING RADON GAS VENTING SYSTEM LS (1.00) $ 7,500.00 LS $ (7,500) SUBTOTAL-PLUMBING $ (7,500) 22 23 PLUMBING&HVAC FCI Constructors,Inc.Confidential Page 40 FC1 Cost Worksheet 7/24/2014/UPDATED 7/31 Project EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,050 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 260000 ELECTRICAL 261000 ELECTRICAL WORK TRI-PHASE ELECTRIC ADMINISTRATION WING SF 5,611.00 $ 23.10 SF $ 292,452 STORAGE/WORK APPARATUS BAYS SF 20,439.00 $ 13.80 SF INCLUDED TEMP LIGHT&POWER SF - $ - SF $ 22,000 800A 480V SECONDARY SERVICE LS 1.00 $ - LS INCLUDED MOTOR&EQUIPMENT CONNECTIONS LS 1.00 $ - LS INCLUDED POWER DISTRIBUTION/BRANCH POWER LS 1.00 $ - LS INCLUDED LIGHTING-FIXTURES-EXTERIOR LS 1.00 $ - LS INCLUDED LIGHTING-FIXTURES-INTERIOR LS 1.00 $ - LS INCLUDED LIGHTING CONTROLS LS 1.00 $ - LS INCLUDED TRIM OUT/FINAL CONNECTIONS LS 1.00 $ - LS INCLUDED FIRE ALARM SYSTEM LS 1.00 $ - LS INCLUDED LIGHTNING PROTECTION SYSTEM LS 1.00 $ 18,000.00 LS INCLUDED DATA/COMMUNICATIONS-CABLE MGT LS 1.00 $ - LS INCLUDED DATA/COMMUNICATIONS-CONDUIT TO PHONE CO PEDESTAL LF 2,200.00 $ 12.00 LF INCLUDED ACCESS CONTROL LS 1.00 $ - LS INCLUDED SECURITY SYSTEM-ROUGH IN ONLY LS 1.00 $ - LS INCLUDED AV SYSTEM-ROUGH IN ONLY LS 1.00 $ - LS INCLUDED STATE ELECTRICAL PERMIT LS 1.00 $ - LS INCLUDED LAYOUT/COORDINATION-ELECTRICAL HRS 173.00 $ 54.00 HRS $ 9,342 EXTERIOR CANOPY GUTTERS& HEAT TAPING EXTERIOR SURFACES DOWNSPOUTS LF 82.00 $ 15.00 LF INCLUDED SEISMIC BRACING ALLOWANCE LS 1.00 $ 3,000.00 LS $ 3,000 SUBTOTAL-ELECTRICAL $ 326,794 260000 ELECTRICAL-TOTALS $ 326,794 COST PER SF $ 12.64 260000 ELECTRICAL FCI Constructors,Inc.Confidential Page 41 • FCI Cost Worksheet 7/24/2014/UPDATED 7/31 Project EAGLE COUNTY REGIONAL AIRPORT-SNOW REMOVAL EQUIPMENT BUILDING(SRE) FINAL DESIGN GMP-REVISION#1 GYPSUM,COLORADO SF 26,060 UNIT OF UNIT PRICE DESCRIPTION MEASURE QUANTITY TOTAL TOTAL 27/280000 LOW VOLTAGE/SPECIAL SYSTEMS 272010 COMMUNICATIONS&DATA CABLE&WIRE TRI-PHASE ELECTRIC COMM/DATA SYSTEM-CABLE&VURE SF 26,050.00 $ 1.00 SF INCLUDED SUBTOTAL-COMMUNICATIONS SYSTEMS $ - 282010 ACCESS CONTROL SYSTEMS TRI-PHASE ELECTRIC ACCESS CONTROL-RELOCATE AT EXTERIOR SECURITY GATE EA 1.00 $ 2,000.00 EA INCLUDED ACCESS CONTROL-DEVICES&WARE MATRIX SYSTEM EA 5.00 $ 4,000.00 EA S 20,000 SUBTOTAL-ACCESS CONTROL $ 20,000 282020 SECURITY SYSTEMS TRI-PHASE ELECTRIC SECURITY SYSTEM-DEVICES&WARE FIXED CAMERAS&CABLE EA 4.00 $ 2,000.00 EA INCLUDED SUBTOTAL-ACCESS CONTROL $ - 27/280000 LV/SPECIAL-TOTALS $ 20,000 COST PER SF $ 0.77 270000 COMM SYSTEMS FCI Constructors,Inc.Confidential Page 42 Snow Removal Equipment Building (SRE) Final Design GMP Estimate-R1 Eagle County Airport Clarifications & Assumptions Gypsum, CO. July 24, 2014 C. Exclusions 1. Unloading, handling, or installation of Owner/User provided materials or equipment unless noted in the documents. 2. Sculptures or artwork. 3. Telephone/data equipment (telephone switching, handsets, PBX units, computers, network servers, printers, scanners, etc.) 4. All loose equipment and furnishings equipment. • Furniture- tables, chairs/seats, desks, modular furniture, demountable office partitions, etc. • Furnishings — loose shelving, filing cabinets, trash bins, loose storage cabinets. • Equipment other than is specifically identified in this estimate. • Vending machines or equipment. 5. All AudioNisual, cabling, equipment. 6. Security system monitoring or alarm elements. 7. Vehicle maintenance equipment. 8. Vehicle wash equipment. 9. Fuel dispensing equipment. 10.All costs associated with attainment of LEED certification. 12. Third party commissioning costs. 2 FCI Constructors,Inc. . Snow Removal Equipment Building (SRE) Final Design GMP Estimate-R1 Eagle County Airport Clarifications &Assumptions Gypsum, CO. July 24, 2014 D. Clarifications/Assumptions Site Work 1. The area of disturbance and development is approximately 2.65 acres. 2. Fill material required under proposed building foundations as well as forming of the building pad is from an on-site stockpile of existing material provided at no cost (other than transport to the project site). It is assumed that the moisture content of the existing structural fill stockpile material is within allowable limits. Therefore, no additional costs are included for drying and spreading of the structural fill material prior to placement and compaction. 3. Site furnishings are excluded- part of Owner FF& E scope/budget. 4. Treatment of finish graded (un-paved) areas within the site areas of disturbance is limited to the scope of work defined on drawing C9.00 (no "landscaping" work indicated). Foundations & Substructure 5. A 4" diameter perimeter foundation drain is included at perimeter of crawl space only. In addition, per direction of the architect, an additional 250 If of non- perforated 4" piping is included to allow for discharge of accumulated water within the foundation drainage system. 6. An under-slab (or crawl space floor) drainage system is not included. 7. Allowances have been included for a crawl space floor and wall membrane liner and exhaust system for"soil gas". 8. All building concrete reinforcing steel is un-coated material (no epoxy or galvanized treatment). 9. Epoxy coated smooth bar dowels are provided at exterior apron pavements. 10. Reinforcing steel at exterior pedestrian walk is standard un-coated material. 11. Over-excavation for the building slab on grade and building foundations has been included to the prescribed depths noted on the structural drawings. No additional allowances have been included for increased depth(s) of excavation. 12. No allowances have been made for anti-corrosion inhibitors (i.e. DCI) as admixtures to site of building concrete. 13. Silica flume additive is not included at any concrete. 3 FCI Constructors,Inc. Snow Removal Equipment Building (SRE) Final Design GMP Estimate-R1 Eagle County Airport Clarifications & Assumptions Gypsum, CO. July 24, 2014 D. Clarifications/Assumptions Foundations & Substructure Superstructure 14.All cold-formed framing elements are included with manufacturer's standard finish. 15.Applied fireproofing of the steel structure is not anticipated and is therefore not included. Exterior Closure 16. Operable sections of the glazed wall assemblies are manually operated. Motor operated units are not included. 17. The translucent glazed wall assemblies are included with manufacturer's standard white (Crystal) color. Panels are 2.75" thick, with a U-value of 0.20. Framing is thermally broken aluminum with a clear anodized finish. Roofing 18.A membrane roofing system (60 mil white TPO) is provided at the Administration wing. The roof assembly includes a base R-value Of 20. Pricing is based on all layers of the roofing insulation being attached to the roof deck substrate simultaneously. The premium cost for attachment of each layer of insulation separately is not included. 20. Roof top equipment screen walls are not included. Interior Construction / Finishes 21. Interior metal stud and drywall partitions are typically included to the roof c-joists above. Framing for non-load bearing is 20-gage material. Walls are included with sound batt insulation place within the stud cavities. The finish on exposed to view drywall is a Level 4 orange peel finish. 4 FCI Constructors,Inc. Snow Removal Equipment Building (SRE) Final Design GMP Estimate-R1 Eagle County Airport Clarifications &Assumptions Gypsum, CO. July 24, 2014 D. Clarifications/Assumptions Interior Construction / Finishes 22. The following types of gypsum board products are not included in this estimate: • Paperless gypsum board. • Abuse or impact resistant gypsum board. 23. Engineering costs for metal stud framing construction are not included. 24. The cost for epoxy tile grout is not included. 25. Fire rated glazing material is not included. Specialties/ Equipment/ Furnishings 26. Interior room identification signage has been included as an allowance. The cost of a site monument sign or building mounted signage or lettering is not included. 27. Corner guards or wall protective surfacing/plating is not included. 28. Loose storage shelving systems are not included. 29.AV equipment is not included (not shown or specified). 30. Visual display boards are not included (not shown or specified). 31. Office work stations are not included. Fire Protection 32.The base bid scope of work includes a dry-pipe system in the Equipment Storage area and a wet pipe system in the Administration office area. Alternate#5 revises the dry-pipe system to a wet pipe system. 33. The cost of fire sprinklers in the crawl space is not included. 34.A fire pump and/or jockey pump is not included. 5 FCI Constructors,Inc. Snow Removal Equipment Building (SRE) Final Design GMP Estimate-R1 Eagle County Airport Clarifications & Assumptions Gypsum, CO. July 24, 2014 D. Clarifications/Assumptions Plumbing 35. Roof overflow drains are not included. Roof overflow capacity is achieved by a through-wall scupper located over the Tools and Parts Storage room. HVAC 37. Water treatment system for HVAC hydronic piping is not included (systems use Glycol in lieu of water). Electrical 39. Per the scope of work indicated on drawing E3.01 (Plan Note #2), a total of two (2) pole mounted site lighting fixtures are included (not the 1 fixture as noted on drawing C2.00). 40. There are a total of four (4) security cameras noted on drawing E2.00 (Plan Note 3). Since the cameras are not specified, an allowance of $8,000 has been included for the purchase of the cameras. Per the notation on E2.00 Cat6 cabling is run from each of the cameras to the telephone back board. No other security system components are included. 41. Emergency power generator scope is limited to the underground conduits run to the location of the unit. No wiring of equipment is included. 42. The cost of emergency radio amplification system is not included. 43. The work associated with the primary electrical service is limited to installation of junction vault at connection to existing, installation of conduit to primary transformer, and trench & backfill for new conduits. Conduit and vault are to furnished at no cost by HCE to the electrician. 44. Lighting fixtures included are "or equal" to the basis of design fixtures & they comply with the Buy America requirements. 46.An allowance of$10,000 has been included for seismic bracing for all MEP work. End of Clarifications &Assumptions. 6 FCI Constructors,Inc. 0 i I E s 4 1 „1 8 A • ffi 1 Y e I t I as 'I1Mg � Y C a I E a o • - I a E { E al n 1 . 1 1 . m � I g 1 t a t ¢c 'II - - _•._1 - 5II x S 1 111 a 6 ` 8 a . o � 21 F 8 2 w 1 m a El i #; i 6 q E t o I T 3 3 7 ! ,- A' i ; : 5 1 3 3 m o d ' 3 3 3' 4 4 a d r � � ry o � � `� � 4 r � 4 � � a o � h a I.. $ $ $ ' $ 8 $ r f $ $ $ $ $ 8 $ o °a $ 8 n 8 $ , , $ , $ < 7 1 pp ry $ w � � U • 3 = v, y [ 8 5 v k m °E E m a 6 m j s e v , - 1 _ a I A m E , m a s $ s Y 1 •m A I A '9 g € s r . a a =11;;. 3 E II, 8 1 22 I E m a n g l Y @ e rc m rc ¢i 1 ? wS L Na a a z a8 a 3 3 $ 3 w S ,� s LL '1 s" 9 .< O 7.,4 T . f i. ........._ --- -._-..--- ......... r .._.._. -- ...._.._. __...--. ... ........... -. - c g _ 1 V_ $ & w i 1 m 8 si 6 $ 1 a s E u e u 5 � S 6 • A 1 1 N y b 8 2 a ! i i F ng E n a* c s -,e 9 E S C a • N a H1LL - _ -..-.. 3 E x E P. l G -t- w 1 :� € j e F .1 ,1 a g 1 ; ' s ' i 1 .. 1 € 2 g E m I ' 0 il g eu F I_ ji - , t • a 3 f i E i 1-411 " 4 1 " " i " 1 " 4HHHH h E 9 3a a a , a a g a a a a , 8 a .. a . a a B m a a a s a a g a , 4 a , i 1 z ° a A4 . w 1€ E e e s 3 % s 1] 1 ° o ° a pY g ` a t 8 1 e LL g ; Ali - a 1 1 F F w a p F ; 8 t 3 ° m 8 S - 9 8 P Y - I I - ; , a S £ LL F o e 1 1 e 13 1 g e 1 F ° 1 ? a F F m u g g i s. I ! 2 g ° A 12 1,0 1 & 2 g 9 e abe g 1 < E g & • g e r e w e 'E - ICI I' W a $ 1 1 i a d s a i ; m I d a aw w a E i ,$ a 4 e a a a e i- a R N 1 s s F s H s 1 1 s s < ' - g. • 7,'.. u S 5 a 1 8LL8 , � � ' IC 1 i g o s i l g ' 3 _ s I11 1. g�j 1 i 2 ► 5 3 t S a —141_. .. ..... .3. 1+13 4 I- - a • 8 S • • i t I • • s • • s rN t s a a a e e e g b e e . _ ' _ :. _ . cc 2 • E Ha o $ $ a a ! a a a a a a , a a a a a 'a a a a 2 4 s "' B LI s g 8 e , £ $ w ' ; a e 3 ca W—E a i i 4 s _ a a 2 i a f a i $ . $ _ 8 I 8 : a s w R R R R i i Li S Q S R CNA SURETY Performance Bond Bond No. 929599675 CONTRACTOR: SURETY:Western Surety Company :SD Corporation (Name,legal status and address) (Name,legal status and principal place of business) FCI Constructors, Inc. 333 S.Wabash Avenue 30701-70 B, Building A 41st Floor Chicago, IL 60604 This document has important legal Grand Junction,CO 81504 consequences. Consultation with OWNER: an attorney is encouraged with (Name, legal status and address) respect to its completion or modification. Eagle County Any singular reference to PO Box 850 Contractor,Surety,Owner or other party shall be considered Eagle, CO 81631 plural where applicable. CONSTRUCTION CONTRACT AlA Document 1+312-2010 Date: December 17,2013 combines two separate bonds,a Four Mdtion Six Hundred Seventy Fax Performance Bond and a Amount: $4,674,863.00 Thousand Epht Hundred sixty Three Doitws and Oo/1oo Payment Bond,into one form. This is not a single combined Description: Performance and Payment Bond. (Name and location) Eagle County Regional Airport Snow Removal Equipment Facility(SRE) BOND Date: August 21, 2014 (Not earlier than Construction Contract Date) Amount` $4,674,863.00 Far M5ion Six Hundred Seventy Four Thousand Eight Hundred sixty Twee oouars and 00/100 Modifications to this Bond: ® None ❑ See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: 1 Corporate Seal) FCI Construc ors, Inc. Western Surety C. y Signature: 4, A Alt Signature: I Name .> Fp ..1 Name `nstin aazar 7 and Title: *(-1.4. ck.a. and Title: Attorney-in-Fact (Any additional signatures appear on the last page of this Performance Bond.) (FOR INFORMATION ONLY—Name,address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: (Architect,Engineer or other party:) US! Colorado LLC 1515 Wynkoop, Suite 200 Denver, CO 80202 800-873-8500 Printed in cooperation with the American Institute of Architects(ALA). The language in this document conforms to the language used in AIR Document A312-Performance Bond 2010 Edition. §T The Contractor and Surety,jointly and severally,bind themselves,their heirs,executors,administrators,successors and assigns to the Owner for the performance of the Construction Contract,which is incorporated herein by reference. §2 If the Contractor performs the Construction Contract,the Surety and the Contractor shall have no obligation under this Bond,except when applicable to participate in a conference as provided in Section 3. §3 If there is no Owner Default under the Construction Contract,the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner,Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference,the Surety may,within five(5)business days after receipt of the Owner's notice, request such a conference. lithe Surety timely requests a conference,the Owner shall attend. Unless the Owner agrees otherwise,any conference requested under this Section 3.1 shall be held within ten (10)business days of the Surety's receipt of the Owner's notice. If the Owner,the Contractor and the Surety agree,the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right,if any,subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default,terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. §4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations,or release the Surety from its obligations,except to the extent the Surety demonstrates actual prejudice. §5 When the Owner has satisfied the conditions of Section 3,the Surety shall promptly and at the Surety's expense take one of the following actions: §5.1 Arrange for the Contractor,with the consent of the Owner,to perform and complete the Construction Contract; §5.2 Undertake to perform and complete the Construction Contract itself;through its agents or independent contractors; §5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract,arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence,to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract,and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default;or §5.4 Waive its right to perform and complete,arrange for completion,or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation,determine the amount for which it may be liable to the Owner and,as soon as practicable after the amount is determined,make payment to the Owner,or .2 Deny liability in whole or in part and notify the Owner,citing the reasons for denial. §6 If the Surety does not proceed as provided in Section 5 with reasonable promptness,the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond,and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4,and the Owner refuses the payment or the Surety has denied liability,in whole or in part,without further notice the Owner shall be entitled to enforce any remedy available to the Owner. Printed in cooperation with the American Institute of Architects(AIA). The language in this document conforms to the language used in AlA Document A312-Performance Bond-2010 Edition. 2 §7 If the Surety elects to act under Section 5.1,5.2 or 5.3,then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract,and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price,the Surety is obligated,without duplication,for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal,design professional and delay costs resulting from the Contractor's Default,and resulting from the actions or failure to act of the Surety under Section 5;and .3 liquidated damages,or if no liquidated damages are specified in the Construction Contract,actual damages caused by delayed performance or non-performance of the Contractor. §8 If the Surety elects to act under Section 5.1,5.3 or 5.4,the Surety's liability is limited to the amount of this Bond. §9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract,and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs,executors,administrators,successors and assigns. §10 The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase orders and other obligations. §11 Any proceeding,legal or equitable,under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond,whichever occurs first. If the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. §12 Notice to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. §13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed,any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. §14 Definitions §14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made,including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled,reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. §14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. §14.3 Contractor Default. Failure of the Contractor,which has not been remedied or waived,to perform or otherwise to comply with a material term of the Construction Contract. §14.4 Owner Default. Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract, §14.5 Contract Documents. Alt the documents that comprise the agreement between the Owner and Contractor. §15 If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. Printed in cooperation with the American Institute of Architects(AM). The language In this document conforms to the language used In AlA Document A312-Performance Bond-2010 Edition. 3 §16 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties,other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Name and Title: Address Address Printed in cooperation with the American institute of Architects(AM). The language in this document conforms to the language used in AM Document A312-Performance Bond-2010 Edition. 4 CNA SURETY Payment Bond Bond No. 929599675 CONTRACTOR: SURETY:Western Surety Company : SD Corporation (Name,legal status and address) (Name,legal status and principal place of business) FCI Constructors, Inc. 333 S.Wabash Avenue 3070 1-70 B,Building A 41st Floor This document has Important legal Grand Junction, CO 81504 Chicago,It.60604 consequences. Consultation with OWNER: an attorney Is encouraged with (Name,legal status and address) respect to its completion or modification. Eagle County Any singular reference to PO Box 850 Contractor,Surety,Owner or other party shall be considered Eagle, CO 81631 plural where applicable. CONSTRUCTION CONTRACT AIA Document A312-2010 Date: December 17, 2013 combines two separate bonds,a Performance Bond and a Amount: $4,674,863.00 rhhousand EygN Hundred Sixty Tk odlars and wino Payment Bond,Into one form. This is not a single combined Description: Performance and Payment Bond. (Name and location) Eagle County Regional Airport Snow Removal Equipment Facility(S RE) BOND Date: August 21, 2014 (Not earlier than Construction Contract Date) our Milian Six Hundred Seventy Four Amount: $4,674,863.00 Thousand Eight Hundred Sixty Three Dollars and 00/100 Modifications to this Bond: ® None ❑ See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Sean Company: (Corporate Seal) FCI Constructors, Inc. Western Surety ' • :ny in Signature: :.1=lilaartat►. Signature: Name E. •as n)P. .) Name n . a -r PP- and Title: _S 1 ii. and Title: Attorney-in-Fact (Any additional signatures appear on the last page of this Payment Bond) (FOR INFORMATION ONLY—Name,address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: (Architect,Engineer or other party:) USI Colorado LLC 1515 Wynkoop, Suite 200 Denver, CO 80202 800-873-8500 Printed In cooperation with the American Institute of Architects MIA). The language In this document conforms to the language used in NA Document A312-Payment Bond•2010 Edition. 5 §1 The Contractor and Surety,jointly and severally,bind themselves,their heirs,executors,administrators,successors and assigns to the Owner to pay for labor,materials and equipment furnished for use in the performance of the Construction Contract,which is incorporated herein by reference,subject to the following terms. §2 If the Contractor promptly makes payment of all sums due to Claimants,and defends,indemnifies and holds harmless the Owner from claims,demands,liens or suits by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the Construction Contract,then the Surety and the Contractor shall have no obligation under this Bond. §3 If there is no Owner Default under the Construction Contract,the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety(at the address described in Section 13) of claims,demands,liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor,materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims,demands,liens or suits to the Contractor and the Surety. §4 When the Owner has satisfied the conditions in Section 3,the Surety shall promptly and at the Surety's expense defend,indemnify and hold harmless the Owner against a duly tendered claim,demand,lien or suit. §5 The Surety's obligations to a Claimant under this Bond shall arise after the following: §5.1 Claimants,who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor,stating with substantial accuracy the amount claimed and the name of the party to whom the materials were,or equipment was,furnished or supplied or for whom the labor was done or performed,within ninety(90)days after having last performed labor or last furnished materials or equipment included in the Claim;and .2 have sent a Claim to the Surety(at the address described in Section 13). §5.2 Claimants,who are employed by or have a direct contract with the Contractor,have sent a Claim to the Surety(at the address described in Section 13). §6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor,that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. §7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2,whichever is applicable,the Surety shall promptly and at the Surety's expense take the following actions: §7.1 Send an answer to the Claimant,with a copy to the Owner,within sixty(60)days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed;and §7.2 Pay or arrange for payment of any undisputed amounts. §7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim,except as to undisputed amounts for which the Surety and Claimant have reached agreement. If,however,the Surety fails to discharge its obligations under Section 7.1 or Section 7.2,the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. §8 The Surety's total obligation shall not exceed the amount of this Bond,plus the amount of reasonable attorney's fees provided under Section 7.3,and the amount of this Bond shall be credited for any payments made in good faith by the Surety. §S Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims,if any,under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond,they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond,subject to the Owner's priority to use the funds for the completion of the work. Printed In cooperation with the American Institute of Architects(AtA). The language In this document conforms to the language used In AIA Document A3i2..Payment Bond-2010 Edition. 6 §10 The Surety shall not be liable to the Owner,Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond,and shall have under this Bond no obligation to make payments to,or give notice on behalf of,Claimants or otherwise have any obligations to Claimants under this Bond. §11 The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to related subcontracts,purchase orders and other obligations. §12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date(1)on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2,or(2)on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract,whichever of(1)or(2)first occurs. If the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. §13 Notice and Claims to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims,however accomplished,shall be sufficient compliance as of the date received. §14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed,any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished,the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. §15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond,tho Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. §16 Definitions §16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done,or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor,materials or equipment was furnished for use in the performance of the Construction Contract; .4 a brief description of the labor,materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor,materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant;and .8 the total amount due and unpaid to the Claimant for labor,materials or equipment furnished as of the date of the Claim. §16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor,materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms labor,materials or equipment"that part of water,gas,power,light,heat,oil, gasoline,telephone service or rental equipment used in the Construction Con tract,architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors,and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor,materials or equipment were furnished. §16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. Printed In cooperation with the American Institute of Architects(AM). The language In this document conforms to the language used In NA Document A312-Payment Bond-2010 Edition. 7 §16.4 Owner Default. Failure of the Owner,which has not been remedied or waived,to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. §16.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. §17 if this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. §18 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties,other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seat) Signature: Signature: Name and Title: Name and Title: Address Address Printed In cooperation with the American Institute of Architects(ALA). The language in this document conforms to the language used in AA Document A312-Payment Bond-2010 Edition. 8 Western Surety Company POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY-IN-FACT Know All Men By These Presents,That WESTERN SURETY COMPANY,a South Dakota corporation,is a duly organized and existing corporation having its principal office in the City of Sioux Falls,and State of South Dakota,and that it does by virtue of the signature and seal herein affixed hereby make,constitute and appoint Douglas C Baesler, Kristin L Salazar,Cory Clauss,Mary E Hanks, Individually of Denver,CO,its true and lawful Attorneys)-in-Fact with full power and authority hereby conferred to sign,seal and execute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature - In Unlimited Amounts- and to bind it thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney,pursuant to the authority hereby given,are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the By-Law printed on the reverse hereof,duly adopted,as indicated,by the shareholders of the corporation. In Witness Whereof.WESTERN SURETY COMPANY has caused these presents to be signed by its Vice President and its corporate seal to be hereto affixed on this 18th day of Lune,2013. .ycr}, WESTERN SURETY COMPANY a to As Das% aui T Bruflat,Vice President State of South Dakota ss County of Minaehaha On this 18th day of June,2013,before me personally came Paul T.Bruflat,to me known,who being by me duly sworn,did depose and say that he resides in the City of Sioux Falls,State of South Dakota;that he is the Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument;that he knows the seal of said corporation;that the seal affixed to the said instrument is such corporate seal,that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority,and acknowledges same to be the act and deed of said corporation. My commission expires t J.MOHR June 23,2015 f NOTARY PIJOLIC SOUTH CUIKOTA { ,/} 4r i 61/A A') J.Mohr,Notary Public CERTIFICATE I,L Nelson,Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in force,and further certify that the By-Law of the corporation pri d on the reverse ereof is -ill in force. In testimRny1 w ereof I have hereunto subscribed my name and affixed the seal of the said corporation this _a day of , !!r��)l� L1� Q,"atnep� WESTERN SURETY COMPANY pPO"4';* z �,S�Ayfp �•••L.Nelson,Assistant Secretary Form F4280,7,2012 ""Ace`, DATE(MAUDDIYYYY) 14.--../ CERTIFICATE OF LIABILITY INSURANCE 8/18/2014 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED,the pollcy(ies)must be endorsed, If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder In lieu of such endorsement(s). PRODUCER NONT CT Ma Clanne_Sewolt US!Colorado,LLC Construction rts4tc°1 E,11800-873-8500 FAX Ne1:303 831-5296 1515 Wynkoop Street EM Suite 200 oDesss:den.contractors@usi.biz Denver CO 80202 INSURER(S)AFFORDING COVERAGE NAIC C INSURER A:Arch insurance Company U 1.50 INSURED FCICON INSURER B:St PauLEi[e_and..Marine Insurance C 24767 FCI Constructors,Inc. INSURERC: PO Box 1767 INSURER D: Grand Junction CO 81502 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER:630661248 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS. EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. tLTR TYPE OP INSURANCE (NCR I wVDRI POLICY NUMBER I IMMIDDYIYYYYI I I1 WD0IDIYEYYY LIMITS A GENERALLJAaILITY FAGLB9175000 0/1/2013 10/1/2014 EACH OCCURRENCE 11,000.000 EMIDAMAGETCTRERTEO COMMERCIAL GENERAL LIABILITY PREMIKS(EayccVnenpl 1100,000 .■CLAIMS-MADE I _,.J OCCUR MED EXP(Any one person) $10,000 ■ PERSONAL,&ADV INJURY S1,000,000 ,J ■. -. GENERAL AGGREGATE 12,000,000 GENt AGGREGATE LIMIT APPLIES PER PRODUCTS•COMPROP AGG 12,000.000 !^ POLICY 1 PZ:4j 7 Lac 1 A AUTOMOBILE LIABILITY ZACAT9155900 10)112013 10/1/2014 CDMIIINED SINGLE LII.NT (Ea scddem) 11,OOD,000 X ANY AUTO BODILY (JURY(Per person) S ALL OWNED SCHEDULED BODILY INJURY(Per acodenl S AUTOS AUTOS N-O 'PROPERLY DAMAGE X AUTOS ED Per PERTY j $ HIRED AUTOS AUTOS 5 8 X UMBRELLALULB OCCUR 2UP15P9635713NF 10/1/2013 10/112014 EACH OCCURRENCE I$25000,000 EXCESS LAB CLAIMS-MADE AGGREGATE $25,000,000 DE0 X RETENTION$10,000 i S A WORKERS COMPENSATION QAWCI9300900 10/1/2013 10/1/2014 X ITOCRYSL1MIU78 101) AND EMPLOYERS'LIABILITY Y 1 N ANY PROPRIETORIPARTNEILEXECUTlVE Ni A E.L.EACH ACCIDENT $1,000,000 OFFICER/MEMBER EXCLUDED? (Mandatory In NH) E L DISEASE-EA EMPLOYEE S1,000,000 , U yea,deecdDe under DESCRIPTION OF OPERATIONS below E .DISEASE•POLICY LIMIT 51,000.000 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES(Attach ACORD 101,Additional Remarks Schedule,If mars apace Is reoWnd) RE: Eagle County Airport—Snow Removal Equipment Building(SRE) As required by written contract or written agreement,the following provisions apply subject to the policy terms,conditions,limitations and exclusions:the Certificate Holder is included as Additional Insured for work,acts or omissions which includes completed operations under the General Liability but only with respect to liability arising out of the Named Insured's work performed on behalf of the certificate holder. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Eagle County ACCORDANCE WITH THE POLICY PROVISIONS. Attn: Rick Ullom,Project Manager PO Box 850 AUTHORIZED REPRESENTATIVE Eagle CO 81631 Villkk\SoOSAIIIWallal. i C)1988-2010 ACORD CORPORATION. All rights reserved. ACORD 25(2010/05) The ACORD name and logo are registered marks of ACORD ACC MCP EVIDENCE OF PROPERTY INSURANCE DATE`NINVDD"YYY' 6/25/2014 THIS EVIDENCE OF PROPERTY INSURANCE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE ADDITIONAL INTEREST NAMED BELOW. THIS EVIDENCE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS EVIDENCE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE ADDITIONAL INTEREST. AGENCY � C AQU.800-973-8500 COMPANY LEILE USI Colorado, LLC Construction Travelers Indemnity Company 1515 Wynkaop Street Suits 200 Denver, CO 90202 aC.Ne303 63i-5295 ADORIESS: den-cantractors00usi.bir CODE; SUB CODE: AGENCY -tcot-I SItHIQMERJR l: INSURED LOAN NUMBER POLICY NUMBER FCI Constructors, OT660142O86.14TIL13 PO Box 1767 Grand Junction, CO 81502 EFFECTIVE DATE EXPIRATION DATE CONTINUED UNTIL li/It' t13 11/1/2 014 1 1 TERMINATED IF CHECKED THIS REPLACES PRIOR EVIDENCE DATED: PROPERTY INFORMATION LOCATION/DESCRIPTION THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS EVIDENCE OF PROPERTY INSURANCE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INFORMATION COVERAGE I PERILS I FORMES j AMOUNT OF INSURANCE OEDUCTIBLE Builder's Risk. - Special Form-Reporting Form Fire Resistive 50,000,000 10,000 Frame/ Joisted Masonry 10,000,000 10,000 Flood a Earth Movement, sub limit 10,000,000 25,000 REMARKS(Including Special Conditions) RE: Eagle County Airport - Snow Removal Equipment Building (SRE) CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. ADDITIONAL INTEREST NAME AND ADDRESS MORTGAGEE ADDITIONAL INSURED LOSS PAYEE Eagle County LOANM Attn: Rick Mum, Project Manager PO Box 850 *,....,. Eagle CO 81031. AUTHORIZED REPRESENTATIVE ACORD 27(2009112) 01993-2009 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD