No preview available
HomeMy WebLinkAboutC08-105AGREEMENT FOR OVERLAY PROJECT THIS AGREEMENT is dated as of the 26th day of March , 2008,by and between Eagle County, Colorado, a body corporate and politic, acting by and through its Board of County Commissioners (hereinafter called "Owner"), and Old Castle SW Group, Inc. d.b.a. B & B Excavating (hereinafter called "Contractor"). Owner and Contractor, in consideration of the mutual covenants set forth, agree as follows: ARTICLE 1 -WORK Contractor shall complete all work as specified or indicated in the Contract Documents ( "Work "). The Work is generally described as: 2008 OVERLAY PROJECT AS SPECIFIED IN EXHIBIT "A" which is attached hereto and incorporated by this reference. ARTICLE 2 - OWNER'S REPRESENTATIVE The Project is under the authority of the Eagle County Road & Bridge Department, the Director of which, or his designee, shall be Owner's liaison with Contractor with respect to the performance of the Work. ARTICLE 3 - CONTRACT TIME 3.1 The Work will be completed and ready for final payment in accordance with the Contract Documents on or before August 31, 2008. 3.2 LIQUIDATED DAMAGES: Owner and Contractor recognize that time is of the essence of this Agreement and that Owner will suffer financial loss if the Work is not substantially complete within the time specified in paragraph 3.1 above, plus any extensions thereof allowed in accordance with the General Conditions. They also recognize the delays, expense, and difficulties involved in proving a legal or arbitration proceeding the actual loss suffered by Owner if the Work is not substantially complete on time. Accordingly, instead of requiring such proof, Owner and Contractor agree that as liquidated damages for delay (but not as a penalty) Contractor shall pay Owner Three Hundred dollars 300.00 for each day that expires after the time specified in paragraph 3.1 for completion until the Work is complete. Agreement Page 1 ARTICLE 4 - CONTRACT PRICE 4.1 The funds appropriated for this project are equal to or in excess of the contract amount. 4.2 Owner shall pay Contractor for performance of the Work in accordance with the Contract Documents in current funds as follows: PROGRESSIVE PAYMENTS UPON COMPLETION OF EACH AREA AS SPECIFIED IN EXHIBIT "A ". 4.3 Pursuant to the provisions §24 -91- 103.6, C.R.S., and notwithstanding anything to the contrary contained elsewhere in the Contract Documents, no change order or other form of order or directive by Owner, and no amendment to this Agreement, requiring additional compensable work to be performed which work causes the aggregate amount payable under the Agreement to exceed the amount appropriated for the original Agreement, shall be of any force or effect unless accompanied by a written assurance by Owner that lawful appropriations to cover the costs of the additional work have been made or unless such work is covered under a remedy - granting provision in the Agreement. 4.4 The Board of County Commissioners for Eagle County is a governmental entity. All obligations beyond the current fiscal year are subject to funds being budgeted and appropriated. ARTICLE 5 - PAYMENT PROCEDURES Contractor shall submit Applications for Payment in accordance with the General Conditions. Applications for Payment will be processed as provided in the General Conditions. 5.1 PROGRESS PAYMENTS: Owner shall make monthly progress payments on account of the Contract Price on the basis of Contractor's Applications for Payments, as provided below. All progress payments will be on the basis of the progress of the Work. 5.1.1 Prior to Completion, progress payments will be in an amount equal to: ❑ 90% of the Work completed until fifty percent (50 %) of the Work is performed, after which no additional retaining shall be withheld, and ❑ 90% of materials and equipment not incorporated in the Work but delivered and suitably stored, less in each case the aggregate of payment previously made. Agreement Page 2 5.1.2 Progress payments and retained funds shall occur in compliance with Paragraph 19 of the General Conditions attached hereto and C.R.S. §24 -91- 103. The Owner shall authorize partial payments of properly requested amounts of at least ninety percent of the calculated value of the work completed until fifty percent of the work required under the Agreement has been performed. Thereafter, the Owner shall authorize partial payments of any other properly requested amounts without retaining additional funds if, in the opinion of the Owner, satisfactory progress is being made in the work. The withheld amounts of the contract price will be retained by the Owner until the contract is completed satisfactorily and accepted by the Owner. 5.2 FINAL PAYMENT: Upon final completion and acceptance in accordance with the General Conditions, Owner shall pay the remainder of the Contract Price. The final payment shall not be made until after final settlement of this contract has been duly advertised at least ten days prior to such final payment by publication of notice thereof at least twice in a public newspaper of general circulation published in Eagle County, and the Board of County Commissioners has held a public hearing, thereupon and complied with the C.R.S. §38 -26 -107. Final payment shall be made in accordance with the requirements of the aforesaid statute. ARTICLE 6 - Contractor's REPRESENTATIONS In order to induce Owner to enter into this Agreement Contractor makes the following representations: 6.1 Contractor has familiarized himself with the nature and extent of the Contract Documents, Work, locality, and with all local conditions, and federal, state, and local laws, ordinances, rules and regulations that in any manner may affect cost, progress, or performance of the Work. 6.2 Contractor has made, or caused to be made, examinations, investigations, and tests and studies of such reports and related data as he deems necessary for the performance of the Work at the Contract Price, within the Contract Time, and in accordance with other terms and conditions of the Contract Documents; and no additional examinations, investigations, tests, reports, or similar data are, or will be required by Contractor for such purposes. 6.3 Contractor has correlated the results of all such observations, examinations, investigations, tests, reports, and data with the terms and conditions of the Contract Documents. 6.4 Contractor has given Owner written notice of all conflicts, errors, or discrepancies that he has discovered in the Contract Documents and the written resolution thereof by Owner is acceptable to Contractor. Agreement Page 3 6.5 In performing the work under this Agreement, the Contractor acts as an independent contractor and is solely responsible for necessary and adequate worker's compensation insurance, personal injury and property damage insurance, as well as errors and omissions insurance. The Contractor, as an independent contractor, is obligated to pay federal and state income tax on moneys earned. The personnel employed by the Contractor are not and shall not become employees, agents or servants of the Owner because of the performance of any work by this Agreement. ARTICLE 7 - CONTRACT DOCUMENTS The Contract Documents which comprise the entire Agreement are made a part hereof, and consist of the following: 7.1 This Agreement. 7.2 Contractor's Bid. 7.3 Performance and other Bonds. 7.4 Notice of Award and, if any, Notice to Proceed. 7.5 General Conditions (Pages 1 to 10, inclusive). 7.6 Specifications and Drawings (if any) 7.7 Any modification, including Change Orders, duly delivered after execution of Agreement. 7.8 The parties acknowledge and agree that the terms and conditions of this Agreement (7.1) and the General Conditions (7.5) attached hereto, shall . supersede and control over any inconsistent or contrary provision in any other attachment or agreement. There are no Contract Documents other than those listed above in this Article 7. The Contract Documents may only be altered, amended, or repealed by an executed, written amendment to this Agreement. ARTICLE 8 - BONDS Not later than five business days following the execution of this Agreement, Contractor shall deliver to the Owner the bonds required by the Contract Documents, and, notwithstanding anything to the contrary contained in the Contract Documents, Owner shall have no liability or obligation hereunder unless and until the bonds have been so delivered. Agreement Page 4 ARTICLE 9 - MISCELLANEOUS 9.1 No assignment by a party hereto of any rights under, or interests in the Contract Documents will be binding on another party hereto without the written consent of the party sought to be bound; and specifically, but without limitation, moneys that may become due and moneys that are due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents. 9.2 Owner and Contractor each binds himself, his partners, successors, assigns and legal representatives to the other party hereto, in respect to all covenants, agreements, and obligations contained in the Contract Documents. 9.3 ATTORNEY'S FEES: In the event of litigation between the parties hereto regarding the interpretation of this Agreement, or the obligations, duties or rights of the parties hereunder, or if suit otherwise is brought to recover damages for breach of this Agreement, or an action be brought for injunction or specific performance, then and in such events, the prevailing party shall recover all reasonable costs incurred with regard to such litigation, including reasonable attorney's fees. 9.4 APPLICABLE LAW: This Agreement shall be governed by the laws of the State of Colorado. Jurisdiction and venue of any suit, right, or cause of action arising under, or in connection with this Agreement shall be exclusive in Eagle County, Colorado. 9.5 INTEGRATION: This Agreement supersedes all previous communications, negotiations and /or contracts between the respective parties hereto, either verbal or written, and the same not expressly contained herein are hereby withdrawn and annulled. This is an integrated agreement and there are no representations about any of the subject matter hereof except as expressly set forth in the Contract Documents. Agreement Page 5 9.6 NOTICE: Any notice and all written communications required under this Agreement shall be (i) personally delivered, (ii) mailed in the United States mails, first class postage prepaid, or (iii) transmitted by facsimile machine together with a hard copy conveyed by delivery or mail, to the appropriate party at the following addresses: County: Board of County Commissioners, Eagle County, Colorado P. O. Box 850 Eagle, CO 81631 Telephone: (970) 328 -8605 Fax: (970) 328 -7207 Contractor: Oldcastle Sw Group, Inc. d.b.a. B &B Excavating P. O. Box 1729 Edwards, CO 81632 With a copy to: Eagle County Road & Bridge P. O. Box 250 Eagle, CO 81631 Telephone: (970) 328 -3540 Fax: (970) 328 -3546 Mailed notices will be deemed given three business days after the date of deposit in a regular depository of the United States Postal Service, and Fax notices will be deemed given upon transmission, if during business hours, or the next business day. Either party can change its address for notice by notice to the other in accordance with this paragraph. 9.7 PROHIBITIONS ON PUBLIC CONTRACT FOR SERVICES. 9.7.1 The Contractor shall not knowingly employ or contract with an illegal alien to perform work under the public contract for services; or enter into a contract with a subcontractor that fails to certify to the Contractor that the subcontractor shall not knowingly employ or contract with an illegal alien to perform work under the public contract for services. 9.7.2 The Contractor shall confirm or attempt to confirm through participation in the Basis Pilot Verification program, as administered by the United States Department of Homeland Security, that the Contractor does not employ any illegal aliens. If the Contractor is not accepted into the Basic Pilot Verification Program prior to entering into a public contract for services, the Contractor shall apply to participate in the Program every three months until the Contractor is accepted or the public contract for services has been completed, whichever is earlier. Information on applying for the Basic Pilot Verification Program can be found at: hftps://www.vis-dhs.com\emploverregistration Agreement Page 6 9.7.3 The Contractor shall not use the Basic Pilot Verification Program procedures to undertake pre - employment screening of job applicants while the public contract for services is being performed. 9.7.4 If the Contractor obtains actual knowledge that a Subcontractor performing work under the public contract for services knowingly employs or contracts with an illegal alien, the Contractor shall be required to: a. Notify the Subcontractor and the County within three days that the Contractor has actual knowledge that the Subcontractor is employing or contracting with an illegal alien; and b. Terminate the Subcontract with the Subcontractor if within three days of receiving the notice required pursuant to subparagraph (i) of the paragraph (d) the Subcontractor does not stop employing or contracting with the illegal alien; except that the Contractor shall not terminate the contract with the Subcontractor if during such three days the Subcontractor provides information to establish that the Subcontractor has not knowingly employed or contracted with an illegal alien. 9.7.5 The Contractor shall comply with any reasonable request by the Department of Labor and Employment made in the course of an investigation that the department is undertaking pursuant to its authority. 9.7.6 If a Contractor violates these prohibitions, the County may terminate the contract for a breach of the contract. If the contract is so terminated, the Contractor shall be liable for actual and consequential damages to the County. 10.00 This Agreement shall be governed by and construed in accordance with the internal laws of the State of Colorado. The Parties agree that venue in any action to enforce or interpret this agreement shall be in the District Court in the Stn District for the State of Colorado. Agreement Page 7 IN WITNESS WHEREOF, the parties have executed this Agreement this day of March, 2008. ATTEST c� Vat ro "SID G B • < Clerk of the Bd6rd of County Commissioners . DLfvr� STATE OF COLORADO County of Eagle EAGLE COUNTY, COLORADO By and through its Board of County Commissioners Peter F. Runyon Chairman "Contractor": Oldcastle SW Group, Inc. d.b.a. B &B Excavating By: ss: The fonoing instrument was acknowledged before me by s Z%AJ , this-22, day of Ml1g .,,; ,,,,.. _ 2008. My commission expi Notary Public. ,OljloPrOiD QR COL 11 COMMWM Expires 0&2&2011 Agreement Page 8 Agreement Page 10 N Z1 a°o n op m ao z =v CL to z V O N 01 O O CD n o 9 m ° m 0v o o� cn -0 0 z o o ..r O O m mm r� r� A x m m O O w w w C) rn ao � o, ao cm 0 lH I I I I I 0 1L] I I Ell o < r � W Po m �v m z X v �. O rC, (D vA vA Mm Mm O O co P N O cfl 4 C" BID FORM PROJECT IDENTIFICATION: 2008 Overlay Project THIS BID IS SUBMITTED TO: Board of County Commissioners Eagle County 500 Broadway Eagle, Colorado 81631 Mailing: Eagle County Road & Bridge Department Attn: Brad.Higgins, Director P. O. Box 250 Eagle, CO 81631 Physical: 3289 Cooley Mesa Road Gypsum, Colorado 81637 1. The undersigned BIDDER proposes and agrees, if this bid is accepted, to enter into an Agreement with OWNER in the form included in the Contract Documents to complete all work as specified or indicated in the Contract Documents for the contract price and within the contract time indicated in this bid and in accordance with the Contract Documents 2. BIDDER accepts all of the terms and conditions of the Instructions to Bidders, including without limitation those dealing with the disposition of bid security. This bid will remain open for thirty (30) days after the day of bid opening. BIDDER will sign the Agreement and submit the contract security and other documents required by the Contract Documents within fifteen (15) days after the date of OWNER'S Notice of Award. 3. In submitting this bid, BIDDER represents, as more fully set forth in the Agreement, that: (a) BIDDER has examined copies of all the Contract Documents and of the following addenda: Date Number (Receipt of all of which is hereby acknowledged) and also copies of the Advertisement of Invitation to Bid and the Instructions to Bidders; (b) BIDDER has examined the site and locality where the work is to be performed, the legal requirements (federal, state, and local laws, ordinances, rules, and regulations), and the conditions affecting cost, progress, or performance of the work, and has made such independent investigations as BIDDER deems necessary; (c) This bid is genuine, and not made in the interest of, or on behalf of, any undisclosed person, firm, or corporation, and is not submitted in conformity with any agreement or rules of any group, association, organization, or corporation; BIDDER has not, directly or indirectly, induced nor solicited any other bidder to submit a false or sham bid; BIDDER has not solicited nor induced any person, firm, or corporation to refrain from bidding; and BIDDER has not sought by collusion to obtain for himself any advantage over any other bidder or over OWNER. 4. BIDDER will complete the work for the following lump sum and unit prices: PLEASE USE EXHIBIT "A" FOR BID PRICES PLEASE USE EXHIBIT "B" FOR SPECIFICATIONS 5. BIDDER agrees that work will be completed on or before August 31, 2008. BIDDER accepts the provisions of the Agreement as to liquidated damages in the event of failure to complete the work on time. 6. The following documents are attached to and made a condition of this bid: (a) Required bid security in the form of a certified or bank check or bid bond. 7. Communication concerning this bid shall be addressed to the address of BIDDER indicated below: ®IdcaStIG SW Group, Inc. _o a_ —__ P.C. Box 1729 �duvarXIs, CO 81 632 Phone Number 7A 331 8. The terms used in this bid which are defined in the General Conditions of the construction contract included as part of the Contract Documents have the meanings assigned to them in the General Conditions. SUBMITTED ON MAC14 S- , 2009. If BIDDER is: An Individual By: . (Individual's Name) Doing business as: Business Number: (SEAL) A Par Phone Number: A Corporation Oldcastle SW Group, Inc, By: d.b.a. B &B Excavating (Corporation Name) C-0 (State of Corporation) (Name of Person Au orized to Sign) : ao = (Title) ',`�O °•�, © �TE SEAL) O�BeBBBBBBB�e,`\ Business Address: Oldcastle SW Group, !; n d.b.a. B &B Excavating P.O. BOX 1-729 Edwards, CO 81632 Phone.Number: q26 33 1 A Joint Venture By: (Name) (Address) By: (Name) (Address) '(Each joint venturer must sign. The manner of signing for each individual, partnership, and corporation that is a parry to the joint venture should be in the manner indicated above) EXHIBIT "A" EAGLE COUNTY 2008 OVERLAY PROJECTS PROJECT #1 Location Description QTY Unit Unit price Amount Upper Kaibab Overlay Polar Star Rd. with 1,967 ton �c� -- 12767? Subdivision 2" of HBP -SX, PG 58-28 Emusified asphalt (tack) 222 gal Overlay Kaibab Rd. with 2" 1023 ton Zy srz — of HBP -SX, PG 58 -28 Construction zone traffic 1 Overlay Fulford Dr. with 2" of 558 ton �p —3� �Z �$� HBP -SX, PG 58 -28 Materials sampling, testing, and insDection. 1 Lump um p� Overlay Green Mtn. Dr. with 217 ton (� iz/ % %% 01 2" of HBP -SX, PG 58 -28 Add shoulder material (3/4" 627 ton *2Z y3 jjt �3 road base 2' wide, 2" deep o Emusified asphalt (tack) 3421 al g� gy 'Z�7 (0 CSS-1 H or SS -1 H Construction zone traffic 1 Lump sum 7� �9y 6s 7 Materials sampling, testing, 1 Lump sum -7.7 Z3s 73 Z35-- and inspection. / Valve box adjustment 19 Lump sum as 1 Z68 'ff TOTAL FOR PROJECT #1 Zql_ 19g 9 PROJECT #2 Location Description QTY Unit Unit price Amount Violet Lane Pave Violet Lane with 4" (in I 7Z o (county road two lifts) of HBP -SX, PG 58- 490 ton #EA5 28 TOTAL FOR PROJECT #2 14W..69? r TOTAL FOR ALL PROJECTS PROJECT NOTES: 1. Manhole and valve box adjustment "lump sum" shall be the cost to adjust the quantities listed. 2. Final manhole and valvebox counts may vary from what is listed. 3. Violet Ln.paving is from RR tracks to bridge (1000ft) 4. Project #2 may be deleted. Add'shoulder material (3/4" 98 ton f� `� 313�]b2, &40 _ road base 2' wide, 4" dee Emusified asphalt (tack) 222 gal 3 3Y 7q/ CSS -1 H or SS -1 H Construction zone traffic 1 Lump sum 4Z,p(17 tl7% yy control Materials sampling, testing, and insDection. 1 Lump um p� Z z6 ��� TOTAL FOR PROJECT #2 14W..69? r TOTAL FOR ALL PROJECTS PROJECT NOTES: 1. Manhole and valve box adjustment "lump sum" shall be the cost to adjust the quantities listed. 2. Final manhole and valvebox counts may vary from what is listed. 3. Violet Ln.paving is from RR tracks to bridge (1000ft) 4. Project #2 may be deleted. I r4 Fidelity and Deposit Company of Maryland Home Office: P.O. Box 1227, Baltimore, MD 21203 -1227 Sam Bond No. 39306 BID BOND KNOW ALL MEN BY THESE PRESENTS: That we, Oldcastle SW Group, Inc. dba B &B Excavating, as Principal, (hereinafter called the "Principal'), and the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, of Baltimore, Maryland, a corporation duly organized under the laws of the State of Maryland, as Surety, (hereinafter called the "Surety "), are held and firmly bound unto Board of County Commissioners - Eagle County as Obligee, (hereinafter called the "Obligee "), in the sum of FIVE PERCENT OF AMOUNT BID Dollars ($5 %), for the payment of which sum well and truly to be made, the said Principal and the said Surety, bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, the Principal has submitted a bid for 2008 Overlay Project NOW, THEREFORE, if the Obligee shall accept the bid of the Principal and the Principal shall enter into a contract with the Obligee in accordance with the terms of such bid and give such bond or bonds as may be specified in the bidding or contract documents with good and sufficient surety for the faithful performance of such contract and for the prompt payment of labor and material furnished in the prosecution thereof, or in the event of the failure of the principal to enter into such contract and give such bond or bonds, if the Principal shall pay to the Obligee the difference not to exceed the penalty hereof between the amount specified in said bid and such larger amount for which the Obligee may in good faith contract with another party to perform the work covered by said bid, then this obligation shall be null and void, otherwise to remain in full force and effect. `N °C�io�� Signed and sealed this 5th day of March A.D. ,2008. Oldcastle SW Group, Inc. dba B &B Excava t a : e, Chip Bair Witness Pat Davis Witness C325 -150M, Approved by The American Institute of Architects, A.I.A. Document No. A -310 February 1970 Edition. Prin' �••C� E Y-� ' B '� �riOftfCC1 Thomas Lyons, G.M. FIDELITY AND DEPOSIT COMPANY OF MARYLAND Surety By (SEAL) Jaso Burkey, Attorney in Fact . r ^ Power of Attorney FIDELITY AND DEPOSIT COMPANY OF MARYLAND KNOW ALL MEN BY THESE PRESENTS: That the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corporation of the State of Maryland, by M. P. HAMMOND, Vice President, and GERALD F. HALEY, Assistant Secretary, in pursuance of authority granted by Article VI, Section 2, of the By -Laws of said Company, are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date a deb by nominate, constitute and appoint Jason BURKEY and Charles E. BAIR, both of Edwards i d lawful agent and Attorney -in -Fact, to make, execute, seal and deliver, for, and t6 eed: Any and all bid bonds issued on behalf of Oldcastle SW Group a av each in a penalty not to exceed the sum of $1,000,000 and the e ,xp ursuance of these presents, shall be as binding upon said Company, as o a ses, as if they had been duly executed and acknowledged by el t off e y at its office in Baltimore, Md., in their own proper persons. The said Assistant t the extract set forth on the reverse side hereof is a true copy of Article VI, Section 2, of the By- ° any, and is now in force. IN WITNESS OF, the said Vice - President and Assistant Secretary have hereunto subscribed their names and affixed the Corporate Seal of the said FIDELITY AND DEPOSIT COMPANY OF MARYLAND, this 5th day of December, A.D. 2006. ATTEST: CEPpsri O � �'WTL State of Maryland 1 ss: City of Baltimore f FIDELITY AND DEPOSIT COMPANY OF MARYLAND X'd -_7 At Gerald F. Haley Assistant Secretary By: QRAZ:�'j M. P. Hammond Vice President On this 5th day of December, A.D. 2006, before the subscriber, a Notary Public of the State of Maryland, duly commissioned and qualified, came M. P. HAMMOND, Vice President, and GERALD F. HALEY, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, to me personally known to be the individuals and officers described in and who executed the preceding instrument, and they each acknowledged the execution of the same, and being by me duly sworn, severally and each for himself deposeth and saith, that they are the said officers of the Company aforesaid, and that the seal affixed to the preceding instrument is the Corporate Seal of said Company, and that the said Corporate Seal and their signatures as such officers were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporation. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above written. POA -F 020-0023D , %11111111, ...'���� � n Maria D. Adamski Notary Public My Commission Expires: July 8, 2007 SURETY ACKNOWLEDGMENT STATE OF CO COUNTY OF EAGLE } SS On this 5th day of March , 2008, before me personally came Jason Burkey to me known, who, being by me duly sworn, did depose and say that she is an Attorney -In -Fact of FIDELITY AND DEPOSIT COMPANY OF MARYLAND the corporation described in and which executed the within instrument; that she knows the corporate seal of said corporation, that the seal affixed to the within instrument is such corporate seal, and that she signed the said instrument and affixed the said seal as Attorney -In -Fact of the Board of Directors of said corporation and by authority of this office under the Standing Resolutions thereof. Notary Public ROAD & BRIDGE DEPARTMENT GENERAL CONDITIONS Contractor shall provide and pay for labor, materials, equipment, tools, utilities, permits, licenses, transportation, and other facilities and services necessary for proper execution and completion of the Work. 2. If Contractor fails to obtain the tax exemption(s) applicable to public works projects from sales, consumer, use and similar taxes, Contractor shall pay the same. Owner will cooperate with Contractor to obtain tax exemption for this project. 3. Contractor shall be responsible for having taken steps reasonably necessary to ascertain the nature and location of the Work, and the general and local conditions which can affect the Work or the cost thereof. Any failure by Contractor to do so will not relieve him from responsibility for successfully performing the Work without additional expense to the Owner. Owner assumes no responsibility for any understanding or representations concerning conditions made by any of its officers, employees or agents prior to the execution of this Agreement, unless such understanding or representations are expressly stated in the Agreement. 4. Before commencing activities, Contractor shall: (1) take field measurements and verify field conditions; (2) carefully compare this and other information known to Contractor with the Agreement; and (3) promptly report errors, inconsistencies or omissions discovered to Owner. 5. Contractor shall supervise and direct the Work, using Contractor's best skill and attention. Contractor shall be solely responsible for and have control over construction means, methods, techniques, quality, sequences and procedures, and for coordinating all portions of the Work. 6. Contractor, as soon as practicable, shall furnish in writing to the Owner the names of subcontractors and suppliers for each portion of the Work. 7. No charge shall be made by Contractor for hindrances or delays from any cause whatever during the progress of any portion of the Work, unless such hindrance or delay is caused in whole or in part by acts or omissions within the control of Owner. In any event, Owner may grant an extension of time for the completion of the Work, provided it is satisfied that delays or hindrances were due to causes outside Contractor's control, e.g., weather, or to acts of omission or commission by the Owner, provided that such extensions of time shall in no instance exceed the time actually lost to Contractor by reason of such causes, and provided further that Contractor shall have given Owner immediate (as determined by the circumstances, but not exceeding 48 hours) notice in writing of the cause of the detention or delay. 8. Contractor shall deliver, handle, store and install materials in accordance with manufacturers' instructions. 9. Contractor shall comply with and give notices required by all federal, state and local laws, statutes, ordinances, building codes, rules and regulations applicable to the Work. If the Contractor performs Work knowing it to be contrary to laws, statutes, ordinances, building codes, rules or regulations without notice to Owner, Contractor shall assume full responsibility for such Work and shall bear the attributable costs. Contractor shall promptly notify Owner in writing of any conflicts between the specifications for the Work and such governmental laws, rules and regulations. 10. The Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs, including all those required by law in connection with performance of the Agreement. The Contractor shall promptly remedy damage and loss to property caused in whole or in part by the Contractor, or by anyone for whose acts the Contractor may be liable. 11. Contractor shall keep the premises /work site and surrounding area free from accumulation of debris and trash related to the Work. 12. Contractor shall furnish performance and payment bonds, each in an amount at least equal to the contract price as security for the faithful performance and payment of all Contractor's obligations under the contract documents. These bonds shall remain in effect at least until two years after the date of final payment, except as otherwise provided by law. Contractor shall also furnish other bonds as are required by the supplementary conditions. All bonds shall be in forms satisfactory to Owner, and be executed by such sureties as (a) are licensed to conduct business in the state where the project is located, and (b) are named in the current list of "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies" as published in Circular 570 (amended) by the Audit Staff Bureau of Accounts, U.S. Treasury Department. All bonds signed by an agent must be accompanied by a certified copy of the authority to act. If the surety on any bond furnished by Contractor is declared bankrupt, or becomes insolvent, or its right to do business is terminated in any state where any part of the project is located, or it ceases to meet the requirements of clauses (a) and (b) of the preceding paragraph, Contractor shall within five days thereafter substitute another bond and surety, both of which shall be acceptable to Owner. 13. Contractor shall be solely responsible for the protection of the Work until its final acceptance by Owner. Contractor shall have no claim against Owner because of any damage or loss to the Work, and shall be responsible for the complete restoration of damaged Work to its original condition. In the event Contractor's Work is damaged by another party, not under his supervision or control, Contractor shall make his claim directly with the party involved. If a conflict or disagreement develops between Contractor and another party concerning the responsibility for damage or loss to Contractor's Work, such conflict shall not be cause for delay in Contractor's restoration of the damaged Work. 14. Contractor's Insurance: The Contractor shall purchase and maintain such insurance as will protect him from claims set forth below which may arise out of or result from the Contractor's operations under the contract, whether such operations be by himself, or by any subcontractor, or by anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them may be liable. All such insurance shall remain in effect until final payment, and at all times thereafter when Contractor may be correcting, removing, or replacing defective Work. In addition, Contractor shall maintain such completed operations insurance for at least two years after final payment, and furnish Owner with evidence of continuation of such insurance at final payment and one year thereafter. Insurance coverage shall be as follows: Claims under Workmen's Compensation, disability benefits, and other similar employee benefit acts, with coverage and in amounts as required by the laws of the State of Colorado; Claims for damage because of bodily injury, occupational sickness or disease, or death of his employees, and claims insured by usual personal injury liability coverage; Claims for damage because of bodily injury, sickness, disease, or death of any person other than his employees; and Claims for damages because of injury to or destruction of tangible property, including loss of use resulting therefrom; Contractor's Liability Insurance issued to and covering the liability for damage imposed by law upon the Contractor and each subcontractor with respect to all Work performed by them under the Agreement; Contractor's Protective Liability Insurance issued to and covering the liability for damages imposed by law upon the Contractor and each subcontractor with respect to all Work under the Agreement performed for the Contractor by subcontractors. Completed Operations Liability Insurance issued to and covering the liability for damage imposed by law upon the Contractor and each subcontractor arising between the date of final cessation of the Work, and the date of final acceptance thereof out of that part of the Work performed by each. Comprehensive Automobile Insurance. All , liability and property damage insurance required hereunder shall be Comprehensive General and Automobile Bodily Injury and Property Damage forms of policies, as the case may be. The Contractor shall in addition, and in the amounts required under the above, obtain protective Liability Insurance issued to and covering the liability for damages imposed by law upon the Owner with respect to all operations under the construction contract by the Contractor or his subcontractors, including omissions and supervisory acts by the Owner. Builder's Risk Insurance: Insofar as the Work to be performed under this contract consists entirely of new construction removed and separated from any existing facility used by Owner, Contractor shall procure and maintain, for the duration of the Work of this project, Builder's Risk Insurance, including the perils of fire, extended coverage (loss due to vehicles, explosion, wind, flood, riot, etc.), vandalism and malicious mischief, and special extended coverage (loss due to falling objects, collapse, water damage from faulty or leaking systems, etc.) in the full amount of the contract price plus the cost of authorized extras. Said amount of insurance coverage shall be considered to cover the insurable value of the Work under this contract which is considered not to exceed one hundred percent (100 %) of the amount of this contract and authorized extras. Such policy shall not insure any tools or equipment, or temporary structures erected at the site and belonging to any person or persons, or their subcontractors who are obliged by contract with the Owner to do Work on the projects. Comprehensive Risk Policy Option: In lieu of the several policies specified for Contractor's Liability Insurance, a comprehensive liability and property damage insurance policy inclusive of all the insurance and requirements herein set forth, subject to the approval of the Owner, will be permissible. Insurance covering claims for damages to persons or property shall at a minimum provide coverage of the larger of (i) $500,000 each person /$1,000,000 each occurrence, for bodily injury and $600,000 each occurrence for property damage , (ii) the maximum liability of a local government provided in the Colorado Governmental Immunity Act, 24 -10 -101, et seq., CRS (1973) as that may be amended from time -to -time, or (iii) such greater amount(s) as may be required by law. Insurance shall be placed jointly in the names of the Owner, Contractor, and any and all subcontractors, and any and all others obliged by contract with the Owner to do Work on this project, and, at the Owner's option, any other person or persons whom the Owner deems to have an insurable interest in said property, or any part thereof, payable as their several interests may appear. Any proceeds obtained from insurance provided for by this paragraph shall be paid to and held by the Owner as trustee. The Owner shall have the right to withhold payment of such proceeds until such time as the Work destroyed or damaged and covered by such insurance shall be reconstructed and shall pay such proceeds on an installment basis similar to that provided for by progress payments covering the original Work. Certificates of Insurance: Certificates of Insurance acceptable to the Owner shall be filed with the Owner prior to commencement of the Work. These Certificates shall contain provisions naming the Owner as an additional insured under Contractor's insurance, as more fully required by the General Conditions herein, and that coverage afforded thirty days prior written not subcontractors shall not pe required insurance have endorsements have been comply with the foregoing Owner's rights hereunder. under the policies will not be cancelled until at least ce has been given the Owner. Contractor and his -mit any of his subcontractors to start Work until all been obtained and certificates with the proper fled with the Owner. Failure of the Contractor to insurance requirements shall in no way waive the 15. Owner, at its option, may purchase and maintain such liability insurance as will protect him against claims which may arise from operations under this contract. Purchasing and maintaining such insurance, however, will not relieve the Contractor from purchasing and maintaining the insurance hereinbefore specified. 16. Before permitting any of his subcontractors to perform any Work under this contract, Contractor shall either (a) require each of his subcontractors to procure and maintain during the life of his subcontracts, Subcontractor's Public Liability and Property Damage Insurance of the types and in the amounts as may be applicable to his Work, which type and amounts shall be subject to the approval of the Owner, or (b) insure the activities of his subcontractors in his own policy. 17. To the fullest extent permitted by law, Contractor shall indemnify and hold harmless Owner, its board, commissioners, employees and the agents of any of them, from and against claims, damages, losses and expenses, including but not limited to attorneys' fees, arising out of or resulting from performance of the Work, provided that such claim, damage, loss or expense is attributable to bodily injury, sickness, disease or death, or to injury to or destruction of tangible property (other than the Work itself) including loss of use resulting therefrom, but only to the extent caused in whole or in part by negligent acts or omissions of the Contractor, a subcontractor, anyone directly or indirectly employed by them or anyone for whose acts they may be liable, regardless of whether or not such claim, damage, loss or expense is caused in part by a party indemnified hereunder. 18. After execution of the Agreement, changes in the Work may be accomplished by Change Order or by order for a minor change in the Work. Owner, without invalidating the Agreement, may order changes in the Work within the general scope of the Agreement consisting of additions, deletions or other revisions. a. No Change Orders or other form of order or directive which requires additional compensable work to be performed may be issued or be effective unless accompanied by a written assurance to the Contractor that lawful appropriations to cover the costs of the additional work have been made. b. A Change Order shall be a written order to the Contractor signed by Owner to change the Work. C. Owner will have authority to order minor changes in the Work not involving changes in the Contract Price or the Contract Time. Such changes shall be written orders and shall be binding on the Contractor and Owner. Contractor shall carry out such written orders promptly. 19. Progress Payments: If the project is subject to progress payments, not more often than once a month, Contractor shall submit to Owner an application for payment filled out and signed by Contractor covering the work completed as of the date of the application, and accompanied by such supporting documentation as Owner may reasonably require. If payment is requested on the basis of materials and equipment not incorporated in the work, but delivered and suitably stored at the site or at another location agreed to in writing, the application for payment shall also be accompanied by such data, satisfactory to Owner, as will establish Owner's title to the material and equipment, and protect Owner's interest therein, including applicable insurance. Each subsequent application for payment shall include an affidavit of Contractor stating that all previous progress payments received on account of the work have been applied to discharge in full all of Contractor's obligations reflected in prior applications for payment. The amount of retainage with respect to progress payments will be as stipulated in the Agreement. Owner will, within ten days after receipt of each application for payment, either indicate in writing a recommendation of payment, or return the application to Contractor indicating in writing its reasons for refusing to recommend payment. In the latter case, Contractor may make the necessary corrections and resubmit the application. Owner shall, within twenty days of recommendation of payment, pay Contractor the amount recommended. 20. Final Payment: Upon written notice from Contractor that the work is complete, Owner will make a final inspection with Contractor, and will notify Contractor in writing of all particulars in which this inspection reveals that the work is incomplete or defective. Contractor shall immediately take such measures as are necessary to remedy such deficiencies. Defects are those identified by an Eagle County Official(s) and shall be judged on quality by that Official(s). After Contractor has completed all such corrections to the satisfaction of Owner, and delivered all maintenance and operating instructions, schedules, guarantees, bonds, certificates of inspection, marked -up record documents or as -built drawings covering all of the Work, Contractor may make application for final payment following the procedure for progress payments. The final application for payment shall be accompanied by all documentation called for in the contract documents, and such other data and schedules as Owner may reasonably require, together with complete and legally effective releases or waivers (satisfactory to Owner) of all liens arising out of, or filed in connection with the work. In lieu thereof, and as approved by Owner, Contractor may furnish receipts or releases in full; an affidavit of Contractor that the releases and receipts include all labor, services, material, and equipment for which lien could be filed, and that all payrolls, material, and equipment bills, and other indebtedness connected with the work, for which Owner or his property might in any way be responsible, have been paid or otherwise satisfied; and consent of the surety, if any, to final payment. If any subcontractor, manufacturer, fabricator, supplier, or distributor fails to furnish a release or receipt in full, Contractor may furnish a bond or other collateral satisfactory to Owner to indemnify Owner against any lien. 21. Final payment shall not become due until Contractor submits to Owner releases and waivers of liens, and data establishing payment or satisfaction of obligations, such as receipts, claims, security interests or encumbrances arising out of the Work. Final payment is subject to the Final Settlement requirements and time periods set forth in C.R.S. §38 -26 -107. 22. Contractor warrants and guarantees that title to all work, materials, and equipment covered by any application for payment, whether incorporated in the project or not, will pass to Owner at the time of payment free and clear of all liens, claims, security interests, and encumbrances (in these General Conditions referred to as "Liens "). 23. Contractor's obligation to perform and complete the Work in accordance with the contract documents shall be absolute. Neither the recommendation of any progress or final payment nor the payment by Owner to Contractor under the contract documents, nor any use or occupancy of the Work or any part thereof by Owner, nor any act of acceptance by Owner, nor any failure to do so, nor any correction of defective Work by Owner shall constitute an acceptance of Work not in accordance with the contract documents or a release of Contractor's obligation to perform the Work in accordance with the contract documents. 24. If Contractor fails to correct Work which is not in accordance with the Agreement, the Owner may direct the Contractor to stop the Work until the correction is made. 25. Contractor shall promptly correct Work rejected by Owner as failing to conform to the requirements of the Agreement and Contractor shall bear the cost of correcting such rejected Work. 26. Contractor warrants to Owner that: (1) materials and equipment furnished under the Agreement will be new and of good quality; (2) the Work will be free from defects not inherent in the quality required or permitted; defects are those identified by an Eagle County Official(s) and shall be judged on quality by that Official(s) and (3) the Work will conform to the requirements of the Agreement. 27. Contractor warrants and guarantees to Owner that all Work will be in accordance with the Contract Documents and will not be defective. Prompt notice of all defects shall be given to Contractor. If, within one year after the date of completion, or such longer period of time as may be set forth in the Agreement (including the Bid), prescribed by law, prescribed by the terms of any applicable warranty given by a materials supplier or required by or a part of the Agreement, any Work is found to be defective, Contractor shall promptly, without cost to Owner, and in accordance with Owner's written instructions, either correct such defective Work, or, if it has been rejected by Owner, remove it from the site, and replace it with nondefective work. If Contractor does not promptly comply with the terms of such instructions, or in an emergency where delay would cause serious risk of loss or damage, Owner may have the defective Work corrected or the rejected Work removed and replaced, and all direct and indirect costs of such removal and replacement, including 'compensation for additional professional services, shall be paid by Contractor. 28. If Contractor defaults or neglects to carry out the Work in accordance with the Agreement and fails within a seven day period after receipt of written notice from the Owner to correct such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies, correct such deficiencies. In such case, the Agreement may be terminated by Owner or a Change Order shall be issued deducting the cost of correction from payments due the Contractor. 29. The performance of the Work may be terminated at any time in whole, or from time to time in part, by Owner for its convenience. Any such termination shall be effected by delivery to Contractor of a written notice ( "Notice of Termination ") specifying the extent to which performance of the Work is terminated and the date upon which termination becomes effective. After receipt of a Notice of Termination, and except as otherwise directed by Owner, Contractor shall, in good faith, and to the best of its ability, do all things necessary, in the light of such notice and of such requests in implementation thereof as Owner may make, to assure the efficient, proper closeout of the terminated Work (including the protection of Owner's property). Among other things, Contractor shall, except as -otherwise directed or approved by Owner: a. stop the Work on the date and to the extent specified in the Notice of Termination; b. place no further orders or subcontracts for services, equipment or materials except as may be necessary for completion of such portion of the Work as is not terminated; C. terminate all orders and subcontracts to the extent that they relate to the performance of Work terminated by the Notice of Termination; d. assign to Owner, in the manner and to the extent directed by it, all of the right, title and interest of Contractor under the orders or subcontracts so terminated, in which case Owner shall have the right to settle or pay any or all claims arising out of the termination of such orders and subcontracts; e. with the approval of Owner, settle all outstanding liabilities and all claims arising out of such termination or orders and subcontracts; and deliver to Owner, when and as directed by Owner, all documents and all property which, if the Work had been completed, Contractor would be required to account for or deliver to Owner, and transfer title to such property to Owner to the extent not already transferred. In the event of such termination, there shall be an equitable reduction of the Contract Price to reflect the reduction in the Work and no cost incurred after the effective date of the Notice of Termination shall be treated as a reimbursable cost unless it relates to carrying out the unterminated portion of the Work or taking closeout measures. \rd &brdge.gc i ., • SPECIFICATIONS 0 DRAWINGS